Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Item 07
Jt4 Date: 18 October 2013 Item No. RESOLUTION APPROVING FEASIBILITY REPORT AND CALLING PUBLIC HEARING FOR THE 2014 STREET RECONSTRUCTION PROJECT Proposed Action Staff recommends adoption of the following motion: Move to approve a resolution approving the feasibility report and calling a public hearing for the 2014 Street Reconstruction Project. These street improvements constitute City Improvement Project 14 -02. Overview On August 19, 2013, the City Council authorized WSB & Associates, Inc. to prepare a feasibility report for the 2014 Street Reconstruction Project areas listed. That feasibility report has been completed. Based on information in the feasibility report, the estimated cost for the 2014 Street Reconstruction Project is $10,236,050. Funding for the 2014 Street Reconstruction Project, based on the City's Street Assessment Policy, is recommended as follows: $2,033,620 City Utility Funds, $5,147,080 City issuance of debt which is repaid with property tax levies and $3,055,350 through special assessments to benefitting property owners. Primary Issues to Consider (see attached) • Citizen Comments • Water Main Replacement Financing the City Share of costs Supporting Information • Project Location Maps and the Feasibility Report are attached. rZ2� Christo r J. Petree Public Works Director Financial Impact: $10,236,050 Budgeted: Yes Source: Refer to City Financing section Related Documents (CIP, ERP, etc.): Notes: PRIMARY ISSUES TO CONSIDER • Citizen Comments: At the neighborhood meetings held on August 1 (in which the entire 2014 Street Reconstruction Project Area was invited) and August 13t (where residents along Flagstaff Avenue, only, were invited to discuss potential traffic calming improvement along Flagstaff Avenue), there was no significant opposition to the project. Concerns regarding the project pertained to drainage, water main replacement, and traffic along Flagstaff Avenue. • Water Main Replacement: The draft 2014 - 2018 Capital Improvement Plan assumed water main replacement costing approximately $1,243,187. However, after analyzing soil samples collected from the Cedar Highlands neighborhood, it was determined that the corrosive nature of the soils and other factors have resulted in design elements that have increased the watermain replacement costs within this portion of the project. As a result the watermain replacement costs are estimated to be $1.95 million. • Project financing. — The City share of cost for street and storm sewer improvements will be financed with the issuance of G.O. Improvement Bonds. The City share of debt will be repaid with tax levies over a 20 year period commencing with taxes payable 2015. — Water main replacement ($1.95 million) is financed from the Water Operating Fund. The preliminary 2014 budget provided $1.24 million for watermain replacement. — Sanitary sewer improvements are estimated at $84,630 which is financed from the Sanitary Sewer Operating Fund. The project cost is anticipated to be within appropriations provided in the preliminary 2014 Sanitary Sewer Operating budget. CITY OF LAKEVILLE RESOLUTION NO: RESOLUTION APPROVING FEASIBILITY REPORT AND CALLING PUBLIC HEARING FOR THE 2014 STREET RECONSTRUCTION PROJECT WHEREAS, on October 21, 2013, the City Council received the feasibility report for the proposed improvements of portions Cedar Highlands First Addition, Cedar Highlands 5th Addition, Dodd Pointe 1 Addition, Dodd Pointe 2 nd Addition, Dodd Pointe 3rd Addition, Donnay's Valley Park 3rd, Donnay's Valley Park 5th, Donnay's Valley Park 7th, Donnay's Valley Park 8 Niakwa Village 2nd Addition and Sunrise Village, City Improvement Project 14 -02. NOW, THEREFORE, BE IT RESOLVED, by the Lakeville City Council: 1. The Feasibility Report for Project 14 -02 is hereby approved. 2. A public hearing is hereby called for November 18, 2013 at 7:00 p.m. at the Council Chambers of the City Hall and the Clerk shall give mailed and published notice of such hearing and improvement as required by law. APPROVED AND ADOPTED this 21s' day of October, 2013. CITY OF LAKEVILLE Matt Little, Mayor ATTEST: Charlene Friedges, City Clerk Peth:-0 &390YG13VAeos{2D14 Shea: Reoomhecliee Pm7etl_1. drstl S.d: S1=13 10. -MM1 � , s City of Lakeville 20195 Holyoke Avenue • Lakeville, MN 55044 FEASIBI LIT Report October 21, 2013 2014 Street Reconstruction Project City of Lakeville Dakota County, Minnesota City Project No. 14 -02 WSB Project No. 2109 -391 - 701 Xenia Avenue South, Suite 300 WSB Minneapolis, MN 55416 Tel: (763) 541 -4800 • Fax: (763) 541 -1700 �- wsbeng.com FEASIBILITY REPORT 2014 STREET RECONSTRUCTION PROJECT CITY PROJECT NO. 14 -02 FOR THE CITY OF LAKEVILLE, MINNESOTA October 21, 2013 Prepared By: WSB & Associates, Inc. 701 Xenia Avenue South, Suite 300 Minneapolis, MN 55416 763 -541 -4800 763 - 541- 1700(Fax) Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 "'dz & Associates, engineering-planning- environmental- construction October 21, 2013 Honorable Mayor and City Council City of Lakeville 20195 Holyoke Avenue Lakeville, MN 55044 Re: Feasibility Report 2014 Street Reconstruction Project City Project No. 14 -02 City of Lakeville, MN W SB Project No. 2109 -3 91 Dear Honorable Mayor and City Council: 701 Xenia Avenue South Suite 300 Minneapolis, MN 55416 Tel: 763 -541 -4800 Fax: 763 -541 -1700 Transmitted herewith for your review is a feasibility report which addresses improvements associated with the 2014 Street Reconstruction Project. This feasibility report describes the necessary improvements and associated costs for this street reconstruction project. We are available at your convenience to discuss this report. Please do not hesitate to contact me at 763 - 287 -7187 if you have any questions regarding this report. Sincerely, WSB & Associates, Inc. k " C'XI Monica Heil, PE Project Manager Enclosure St. Cloud • Minneapolis • St. Paul Equal Opportunity Employer wsbeng.com CERTIFICATION I hereby certify that this plan, specification, or report was prepared by me or under my direct supervision and that I am a duly Licensed Professional Engineer under the laws of the State of Minnesota. Monica Heil, Date: October 21, 2013 Lic. No. 47497 Quality Control Review Completed By: Tom Kgllogg, Date: October 21, 2013 Lic. No. 26917 Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 TABLE OF CONTENTS TITLE SHEET LETTER OF TRANSMITTAL CERTIFICATION SHEET TABLE OF CONTENTS 1. EXECUTIVE SUMMARY ................................................................. ..............................1 2. STREET AND UTILITY IMPROVEMENT PROJECT ................ ..............................3 2.1 Introduction ................................................................................ ..............................3 2. 1.1 Authorization ................................................................. ..............................3 2.1.2 Scope .............................................................................. ..............................3 2.1.3 Data Available ............................................................... ..............................3 2.2 General Background .................................................................. ..............................4 2.2.1 Project Location ............................................................. ..............................4 2.3 Existing Conditions .................................................................... ..............................5 2.3.1 Roadway Surface ........................................................... ..............................5 2.3.2 Storm Sewer ................................................................... ..............................8 2.3.3 Water Main .................................................................... ..............................9 2.3.4 Sanitary Sewer .............................................................. .............................10 2.3.5 Wetlands ....................................................................... .............................10 2.4 Proposed Improvements ........................................................... ..............................1 l 2.4.1 Roadway Surface .......................................................... .............................11 2.4.1.1 Flagstaff Avenue Traffic Calming .............. ............................... 12 2.4.1.2 Sidewalk Improvements .............................. ............................... 13 2.4.2 Storm Sewer .................................................................. .............................14 2.4.3 Water Main Improvements ........................................... .............................15 2.4.4 Sanitary Sewer Improvements ...................................... .............................15 2.4.5 Street Sign Replacement ............................................... .............................16 2.4.6 Mailbox Replacement ................................................... .............................16 2.4.7 Permits / Approvals ......................................................... .............................16 2.4.8 Construction Access /Staging ........................................ .............................16 2.4.9 Public Involvement ....................................................... .............................17 3 . FINANCING ....................................................................................... .............................18 3.1 Opinion of Cost ......................................................................... .............................18 3.2 Funding ..................................................................................... .............................18 4. PROJECT SCHEDULE ..................................................................... .............................20 5. FEASIBILITY AND RECOMMENDATION ................................. .............................21 Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 TABLE OF CONTENTS (continued) Appendix A Figure 1: Location Map Figure 2: Typical Section — Residential Streets Figure 3: Typical Section — Residential Streets — Cedar Highlands Figure 4: Typical Section — Collector Streets — 164 Street /Finch Way /162 Street and Fairgreen Avenue Figure 5: Typical Section — Collector Streets — Foliage Avenue and Flagstaff Avenue Figure 6: Typical Section — Collector Streets — 170 Street Figure 7: Concept Flagstaff Avenue Improvements Appendix B Opinion of Probable Cost Appendix C Assessment Map ID — Valley Park and Niakwa Village Assessment Map ID — Cedar Highlands and Dodd Pointe Assessment Roll Appendix D 2013 Geotechnical Report — Log of Test Borings Appendix E Neighborhood Informational Meeting Minutes — August 13, 2013 August 13, 2013, Public Comment Summary Flagstaff Avenue Public Comment Summary Appendix F Soil Corrosivity Results /Past Project Comparison Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 1. EXECUTIVE SUMMARY The 2014 Street Reconstruction Project, City Project No. 14 -02, was initiated based on the City's Pavement Management Program. Streets proposed for improvements in 2014 include the following roadways totaling approximately 41,800 feet (7.90 miles): Cedar Highlands l i t and 5 Additions ■ Garcia Way West (Gerdine Path to 170 Street West) ■ 170 Court West (cul -de -sac located on the south side of 170 Street West at Garcia Way West) ■ 170 Street West (Cedar Avenue /CSAH 23 to Gerdine Path) ■ Georgetown Way (loop street south of and adjacent to 170 Street; east of Cedar Avenue; west of Gerdine Path) ■ Georgetown Way (cul -de -sac located on north side of 170 Street West) ■ Georgetown Court (cul -de -sac located on southeast side of Georgetown Way) Dodd Pointe 0 and 3 r d Additions • Excelsior Drive (160 Street South /CSAH 46 to Dodd Lane southern access) • Excelsior Court (cul -de -sac located on east side of Excelsior Drive) • Excelsior Circle (cul -de -sac located on the southwest side of Excelsior Drive) • Dodd Lane (Excelsior Drive to Dodd Boulevard /CSAH 9) • Excel Way (160 Street /CSAH 46 westerly access to 160 Street /CSAH 46 easterly access) Valley Park 3 d�tn�tn, and S t e Additions and Sunrise Village ■ Foliage Avenue (Gerdine Path to Upper 162 Street West) ■ 169 Street West (Dodd Boulevard /CSAH 9 to Flagstaff Avenue West) ■ Lower 169 Street West (169 street West to Florin Avenue West) ■ Flounder Court (cul -de -sac located on south side of Lower 169 Street West) ■ Florin Avenue West (Lower 169 Street West to 169 Street West) ■ Flagstaff Avenue (160 Street /CSAH 46 to Dodd Boulevard /CSAH 9) ■ 163 Street West (Flagstaff Avenue to Fishing Avenue West) ■ Fishing Avenue West (Lower 161 Street West to Flagstaff Way West) ■ Lower 161 Street West (Fishing Avenue West to Fairgreen Avenue) ■ Finland Avenue West (Fishing Avenue West to Lower 161 Street West) ■ Fishing Way West (Fishing Avenue West to 162 street West) ■ 162 Street West (Finland Avenue West to Fairgreen Avenue) ■ 161 Street West (Finland Avenue West to Fairgreen Avenue) ■ 164 Street West (Flagstaff Court to Fishing Avenue West) ■ Finch Way West (Fishing Avenue West to Finch Avenue West) ■ Finch Avenue West (160 Street /CSAH 46 to Finch Way West) ■ Fairgreen Avenue (160 Street /CSAH 46 to Dodd Boulevard/CSAH 9) ■ Fernando Way (Fishing Avenue West to 162 Street West) ■ Fernando Way (cul -de -sac located north of Fernando Way) Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 1 • Flagstaff Way West (Flagstaff Avenue West to Fernando Way) • Finesse Way (Flagstaff Way West to Dodd Boulevard /CSAH 9) • Farcry Way (Fernando Way to Dodd Boulevard /CSAH 9) • Fantasia Avenue (162 Street West to Farcry Way) • Findlay Way West (Fernando Way to Finch Way West) Niakwa Village 2 n d Addition • Flagstaff Court North (cul -de -sac located on west side of Flagstaff Avenue) • Flagstaff Court South (cul -de -sac located on southwest side of Flagstaff Court North) The 2014 Street Reconstruction Project includes roadway reclamation improvements based on the current roadway conditions and the overall Capital Improvement Plan budget. Reclamation of the existing bituminous pavement and roadway reconstruction, consisting of pavement subgrade correction, concrete curb and gutter replacement, structurally deficient concrete sidewalk replacement, and new pavement installation, are recommended for all streets within the project area. Replacing portions of the City's deteriorating utility infrastructure in conjunction with the proposed street improvements provides an opportunity to minimize the replacement costs and traffic disruptions associated with the work. Proposed utility improvements include the following: • Repair or replacement of damaged or deficient sanitary sewer manholes • Replacement of existing water main including hydrants, gate valves, and services • Repair or replacement of structurally deficient storm sewer manholes • Installation of additional storm sewer drainage structures and storm sewer, including draintile in area with poorly draining soils • Replacement of all existing storm sewer and sanitary sewer manhole castings that do not meet current City Standards The total estimated project cost for the 2014 Street Reconstruction Project is $10,236,050 which includes a 6.5% contingency and 28% indirect costs for legal, engineering, administrative, and financing costs. The project is proposed to be funded through special assessments to benefitting property owners and City funds. The project is proposed to be substantially completed in 2014, including restoration items. The project is feasible, necessary, and cost - effective from an engineering standpoint and should be constructed as proposed herein. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 2 2. STREET AND UTILITY IMPROVEMENT PROJECT 2.1 Introduction 2.1.1 Authorization On August 19, 2013, the Lakeville City Council authorized the preparation of an engineering feasibility report for the 2014 Street Reconstruction Project. This project is included in the City's draft 2014 — 2018 Capital Improvement Plan (CIP) and has been designated as City Project No. 14 -02. 2.1.2 Scope This report investigates the feasibility of proposed street and utility improvements identified by the City's Pavement Management Program and Capital Improvement Plan for 2014. Streets proposed within the 2014 Street Reconstruction Project were initially considered because of existing pavement conditions and known utility issues. The average Overall Condition Index (OCI) value for streets within the 2014 Street Reconstruction Project area is 18 using an OCI scale of 0 to 100 (with zero representing a failing street section and 100 representing a new street section free of deficiencies). Streets with OCI values less than 35 are considered to be in failing condition. Improvements outlined within this report include bituminous pavement reclamation and reconstruction, water main replacement, sanitary sewer manhole repairs, and storm sewer improvements, including draintile in areas with poorly draining soils. 2.1.3 Data Available Information and materials used in the preparation of this report include the following: • City of Lakeville Record Plans • City of Lakeville Water Main Repair Records • City of Lakeville Water Resources Management Plan, Barr Engineering, dated June 2008 • Dakota County Topography Maps • FEMA Floodplain Maps, dated December 2, 2011 • Field Observations of the Area and Discussions with City Staff • Geotechnical Evaluation Report, Braun Intertec, dated October 2013 • Televising Reports for the Sanitary Sewer System (Completed by the City of Lakeville) • Utility Record Drawings • Water Main Leak Survey (Completed by Water Conservations Services, Inc.) • City of Lakeville Street Reconstruction Assessment Policy Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 3 2.2 General Background 2.2.1 Project Location The streets proposed for improvements include: Cedar Highlands l i t and 5 1h Additions ■ Garcia Way West (Gerdine Path to 170 Street West) ■ 170 Court West (cul -de -sac located on the south side of 170 Street West at Garcia Way West) ■ 170 Street West (Cedar Avenue /CSAH 23 to Gerdine Path ■ Georgetown Way (Loop street south of and adjacent to 170 Street; east of Cedar Avenue; west of Gerdine Path) ■ Georgetown Way (cul -de -sac located on north side of 170 Street West) ■ Georgetown Court (cul -de -sac located on southeast side of Georgetown Way) Dodd Pointe 1 St, 2nd, and 3 r d Additions • Excelsior Drive (160 Street South /CSAH 46 to Dodd Lane southern access) • Excelsior Court (cul -de -sac located on east side of Excelsior Drive) • Excelsior Circle (cul -de -sac located on the southwest side of Excelsior Drive) • Dodd Lane (Excelsior Drive to Dodd Boulevard /CSAH 9) • Excel Way (160 Street /CSAH 46 westerly access to 160 Street /CSAH 46 easterly access) Valley Park 3 d , 5 hith, and 8 t h Additions and Sunrise Village ■ Foliage Avenue (Gerdine Path to Upper 162 Street West) ■ 169 Street West (Dodd Boulevard /CSAH 9 to Flagstaff Avenue West) • Lower 169 Street West (169 street West to Florin Avenue West) • Flounder Court (cul -de -sac located on south side of Lower 169 Street West) • Florin Avenue West (Lower 169 Street West to 169 Street West) ■ Flagstaff Avenue (160 Street/CSAH 46 to Dodd Boulevard /CSAH 9) ■ 163 Street West (Flagstaff Avenue to Fishing Avenue West) • Fishing Avenue West (Lower 161 Street West to Flagstaff Way West) • Lower 161 Street West (Fishing Avenue West to Fairgreen Avenue) • Finland Avenue West (Fishing Avenue West to Lower 161 Street West) ■ Fishing Way West (Fishing Avenue West to 162 street West) ■ 162 Street West (Finland Avenue West to Fairgreen Avenue) ■ 161 Street West (Finland Avenue West to Fairgreen Avenue) ■ 164 Street West (Flagstaff Court to Fishing Avenue West) ■ Finch Way West (Fishing Avenue West to Finch Avenue West) ■ Finch Avenue West (160 Street /CSAH 46 to Finch Way West) ■ Fairgreen Avenue (160 Street/CSAH 46 to Dodd Boulevard /CSAH 9) ■ Fernando Way (Fishing Avenue West to 162 Street West) ■ Fernando Way (cul -de -sac located north of Fernando Way) Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 4 • Flagstaff Way West (Flagstaff Avenue West to Fernando Way) • Finesse Way (Flagstaff Way West to Dodd Boulevard /CSAH 9) • Farcry Way (Fernando Way to Dodd Boulevard /CSAH 9) • Fantasia Avenue (162 Street West to Farcry Way) • Findlay Way West (Fernando Way to Finch Way West) Niakwa Village 2 Ad d Addition • Flagstaff Court North (cul -de -sac located on west side of Flagstaff Avenue) • Flagstaff Court South (cul -de -sac located on southwest side of Flagstaff Court North) The project areas are shown on Figure I of Appendix A of this report. 2.3 Existing Conditions 2.3.1 Roadway Surface Streets within the proposed improvement area are aging and experiencing various severities of distresses including alligator, block, transverse, and longitudinal cracking, along with localized drainage issues. All project areas contain landscaping, trees, and numerous other private improvements beyond the edge of the roadway and within City right -of -way. Concrete sidewalks of varying widths (between 48 inches and 60 inches) are located throughout the project area. Generally speaking, the sidewalk located within Cedar Highlands 5 th Addition (along 170 Street) is 60 inches wide; all other sidewalk within the project area is 48 inches wide. The City's current standard for sidewalk widths is 60 inches. Some of the existing sidewalk panels within the 2014 Street Reconstruction Project area have heaved due to the proximity of the root systems of mature trees within close proximity of sidewalks. Additionally, several of the sidewalk panels within the project area are aging and showing various signs of structural distress, such as spalling, cracking, and faulted joints. The majority of pedestrian curb ramps within the project area do not meet current ADA accessible design standards. Table 1 beginning on the following page provides a summary of existing street conditions within the 2014 Street Reconstruction Project. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 5 Table 1— 2014 Street Reconstruction Project Summary of Existing Street Conditions Approx. Street Name ROW Street Curb Sub -grade Sub -base Avg. Bit. Year of Width Type (aggregate) Section Original Construction CEDAR HIGHLANDS 1 sT AND 5 TH ADDITIONS Garcia Way West 60' 32' B -B D412 Lean clay with 10" - 17.5" 3.5" - 5.5" 1978 No boring No boring No boring 170 Court West 60'- 120' 32' B -B D412 information information information 1978 available available available 170 Street West 60'- 80' 32'- 44' D412 Poorly graded 6" - 10" 4" - 4.5" 1994 B -B sand with silt Fill: Poorly Georgetown Way 60' 32' B -B D412 graded sand 8" 3" 1994 with silt Georgetown Way (cul -de- No boring No boring No boring sac) 60' - 120' 32' B -B D412 information information information 1994 Georgetown Court 60' 32' B -B D412 No boring No boring No boring 1994 information information information DODD POINTE 1 sT , 2 ND , AND 3 RD ADDITIONS Excelsior Drive 60' 32' B -B D412 Fill: Silty sand 6.5" 2" 1984, 1986 Excelsior Court 60'- 120' 32' B -B D412 No boring No boring No boring 1984 information information information Excelsior Circle 60'- 120' 32' B -B D412 No boring No boring No boring 1984 information information information Dodd Lane 60' 32' B -B D412 Poorly graded 10" 4" 1986 sand with silt Excel Way 60' 32' B -B D412 Poorly graded 2.5" 3.5" 1986 sand with silt VALLEY PARK 3 RD , 5 TH , 7 TH , AND 8 TH ADDITIONS AND SUNRISE VILLAGE Foliage Avenue 80' 40' F -F B618 Fill: Clayey 10" 4" 1969 sand Fill: Poorly 169 Street West 60' 33' B -B D412 graded sand 12" 3" 1971 with silt Fill: Poorly Lower 169 Street West 60' 34' B -B D412 graded sand 21" 3" 1971 with silt No boring No boring No boring Flounder Court 60'- 120' 34'- 94' D412 information information information 1971 B B available available available No boring No boring No boring Florin Avenue West 60' 34' B -B D412 information information information 1971 available available available Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 6 Table 1— 2014 Street Reconstruction Project Summary of Existing Street Conditions Approx. Street Name ROW Street Curb Sub -grade Sub -base Avg. Bit. Year of Width Type (aggregate) Section Original Construction Fill: Poorly Flagstaff Avenue 110' 41'13-13 D412 graded sand 5.5" - 6.5" 5" - 6.5" 1971, 1972 with silt Fill: Poorly 163' Street West 60' 33'13-13 D412 graded sand 10" 3" 1972 with silt Fishing Avenue West Fill: Silty sand (Lower 161 st Street West 60' 34'13-13 D412 and clayey 3.5" - 10.5" 2.5" - 4" 1972 to 163rd Street West) sand Lower 161 Street West 60' 31'13-13 D412 Fill: Silty sand 8.5" 3" 1986, 1987 Finland Avenue West 60' 34'13-13 D412 Fill: Silty sand 3.5" 2.5" 1972 Fishing Way West 60' 33'13-13 D412 Fill: Clayey 15.5" 3.5" 1972 sand 162nd Street West No boring No boring No boring (Finland Avenue West to 60' 33'13-13 D412 information information information 1972 Finch Avenue West) available available available 162 Street West (Finch Avenue to Fairgreen 80' 41'13-13 D412 Poorly graded 4" 3.5" 1983 Avenue) sand with silt Fill: Poorly 161 Street West 60' 32'13-13 D412 graded sand 3.5" 2.5" 1986 with silt VALLEY PARK 3 RD , 5 TH , 7 TH , AND 8 TH ADDITIONS AND SUNRISE VILLAGE Fill: Poorly 164th Street West 80' 40'13-13 B618 graded sand 10" 3" 1972 with silt Finch Way West 80' 40'13-13 D412 Fill: Silty sand 0" * 2.5 1972 Finch Avenue West 60' 32'13-13 D412 Poorly graded 5" 3" 1986 sand with silt Fill: Poorly Fairgreen Avenue 80' 44'13-13 D412 graded sand 6.5" - 7" 3" - 5.5" 1983, 1986 with silt Fill: Poorly Fernando Way 60' 34'13-13 D412 graded sand 3.5" - 5.5" 2.5" - 3" 1972, 1983 with silt 33'- 94' No boring No boring No boring Fernando Way cul -de -sac 60'- 120' 13-13 D412 information information information 1972 available available available Flagstaff Way West 60' 33'13-13 D412 Fill: Silty sand 8.5" 2.25'- 3" 1972 Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 7 Table 1— 2014 Street Reconstruction Project Summary of Existing Street Conditions Approx. Street Name ROW Street Curb Sub -grade Sub -base Avg. Bit. Year of Width Type (aggregate) Section Original Construction No boring No boring No boring Finesse Way 60' 33'13-13 D412 information information information 1972 available available available No boring No boring No boring Farcry Way 60' 32' B -B D412 information information information 1983 available available available Fill: Poorly Fantasia Avenue 60' 32'13-13 D412 graded sand 3" 3" 1983 with silt No boring No boring No boring Findlay Way West 60' 34' B -B D412 information information information 1972 available available available NIAKWA VILLAGE 2' ADDITION 32'- 90' Fill: Poorly Flagstaff Court North 60'- 120' B B D412 graded sand 0" * 3.5" 1981 with silt 25' - 33' Fill: Poorly Flagstaff Court South 40'- 60' B B D412 graded sand 0" * 3.5" 1981 with silt * Sub -base not distinguishable from subgrade. A copy of the geotechnical soil boring logs may be found in Appendix D of this report. 2.3.2 Storm Sewer City record drawing information indicates that some storm sewer facilities already exist throughout the 2014 Street Reconstruction Project area. Runoff collected by the existing catch basins travels through existing storm sewer pipe and outlets into: Regional Stormwater Basin SC -34 -1, which is located within the Cedar Highlands Neighborhood south of 170 Street West, north of Dodd Boulevard, and west of Gerdine Path. The majority of 170 Street, a portion of Garcia Way, the eastern half of Georgetown Way, the Georgetown Way cul -de -sac, and Georgetown Court drain to this regional stormwater basin. Regional Stormwater Basin SC -39 -1, which is located west of Cedar Avenue; south of 170 Street, east of Glenwood Avenue, and west of Glencoe Avenue, within the Shady Oak Shores development. A portion of 170 Street, a portion of Garcia Way, the western half of Georgetown Way, and 170 Court drain to this regional stormwater basin. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 8 Regional Stormwater Basin SC -15 -1, which is located north of and adjacent to 165 Street; west of and adjacent to Pilot Knob Road (CSAH 31). Excel Way, Dodd Lane, Excelsior Drive, Fairgreen Avenue, 161 Street, Lower 161 st Street, 162 Street, Fantasia Avenue, Farcry Way, portions of Fishing Way, 163 Street, Finland Way, Fishing Avenue, Finch Way, and Fernando Way drain to this regional stormwater basin prior to outletting into East Lake. A portion of Garcia Way, the streets located within the Dodd Pointe Neighborhood (Lower 169 Street West, 169 Street West, Florin Avenue, and Flounder Court), Flagstaff Avenue, Flagstaff Court North, Flagstaff Court South, Foliage Avenue, Flagstaff Way, Finesse Way, and portions of Fishing Way, 163 Street, Finland Way, Fishing Avenue, 164 Street, Finch Way, and Fernando Way all drain directly into tributaries of the North Creek drainage channel_ Historically, the majority of the existing storm sewer facilities within the proposed project area have proven adequate during smaller rainfall events. At the August 13, 2013, Neighborhood Meeting, some residents approached City staff with concerns regarding localized drainage issues throughout the project. Within the Valley Park area, a number of poorly draining streets and intersections, where limited storm sewer currently exists, were identified, including: • Fernando Way • Excelsior Drive at Excelsior Circle • Flagstaff Avenue at 163 Street West 2.3.3 Water Main The majority of the existing water main located within the 2014 Street Reconstruction Project is cast iron pipe (CIP). Ductile Iron Pipe (DIP) was used within portions of the project where, generally speaking, the streets were constructed after 1980. Six -inch water main pipe exists within the majority of the project area; however, the following roadways have been identified as having water main pipe diameters larger than 6 inches: 8 -inch Water Main (CIP and DIP): • Flagstaff Avenue between Dodd Boulevard and 163 Street West • Lower 161 Street • Foliage Avenue • Georgetown Way between Georgetown Court and 170 Street 12 -inch Water Main (CIP and DIP): ■ 162 Street • Fairgreen Avenue • Finch Way • 170 Street • Georgetown Court • Georgetown Way between 170 Street Georgetown Court Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 9 • Georgetown Way cul -de -sac • Excelsior Drive between Dodd Lane and Excelsior Circle • Excelsior Circle • Excel Way along the south end of the curve City maintenance records indicate a total of one (1) recorded water main break along Garcia Way (west of the replacement work completed in 2012 where four (4) breaks had been previously recorded), two (2) along Flagstaff Avenue between Dodd Boulevard and Flagstaff Way, and two (2) within the remaining project area. Water main breaks along Garcia Way and Flagstaff Avenue have led to long -term and costly maintenance issues for the City. The age of the existing pipe along Garcia Way would not suggest that the water main breaks are simply the result of an aging infrastructure. Soil samples were collected with the geotechnical borings earlier this fall to test for corrosivity in the soils (pH, oxidation - reduction, electrical resistivity, chloride content, and sulfate content) to determine if the native soils were contributing to failure, or future failure, of water main pipe in this area. The results of the corrosivity testing indicate that the soils are similar to the corrosive soils encountered within the 2012 and 2013 Street Reconstruction Projects, where more extensive break histories had been recorded for the older pipes. A summary of the corrosivity testing results can be found in Appendix F. The City also conducted a leak detection survey and evaluated all of the water main valves and hydrants within the project during the fall of 2013. 2.3.4 Sanitary Sewer The majority of the existing sanitary sewer located within the 2014 Street Reconstruction Project consists of 9 -inch vitrified clay pipe (VCP) within the roadways originally constructed prior to 1980, and 8 -inch polyvinyl chloride pipe (PVC) within the remaining local roadways. Twelve -inch reinforced concrete pipe (RCP) exists along Flagstaff Way and Flagstaff Avenue, between Dodd Boulevard and Gerdine Path. In the fall of 2013, the City's Public Works Department televised the sanitary sewer and inspected all of the sanitary sewer manholes. Nearly all of the sanitary sewer manholes were identified as needing new rings and /or castings and are proposed to be repaired as a part of this project. 2.3.5 Wetlands No wetland impacts are anticipated with the proposed improvement project. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 10 2.4 Proposed Improvements 2.4.1 Roadway Surface Surface improvements proposed with the 2014 Street Reconstruction Project include the reclamation of all roadways. Reclamation is the process by which the existing deteriorating roadway surface is reused as aggregate roadway base for the new street section. Street grades are proposed to very closely match the existing grades so as to minimize construction impacts to adjacent properties. Minor adjustments to the some of the existing roadway vertical profiles will be proposed to improve drainage conditions. The local residential streets within the project area will be reclaimed and reconstructed in accordance with City design standards, and are proposed to consist of the following section: 1 1 /2 inches of bituminous wearing course, 2 inches of bituminous base course, and 6 inches of reclaimed aggregate base over 12 inches of an acceptable, compacted subgrade. Figure 2 of Appendix A illustrates the proposed roadway section. Garcia Way and 170 Court, which were constructed with the Cedar Highlands 1st Addition improvements in 1978, are showing a high level of pavement distress, and due to the nature of the underlying soils found in this area, complete roadway reconstruction is recommended. Complete roadway reconstruction is also proposed along 170 Street, Georgetown Way, and Georgetown Court, which were constructed in 1994 with the Cedar Highlands 5 th Addition improvements, due to proposed water main improvements and characteristics of the soils within the area. Garcia Way, 170 Court, Georgetown Way, and Georgetown Court all currently measure 32 feet in width, as measured from back -to -back of curb. The aforementioned streets will all be reclaimed and reconstructed to the City's current local roadway design standard, and are proposed to consist of the following section: 1 1 /2 inches of bituminous wearing course, 2 inches of bituminous base course, 6 inches of Class 5 aggregate base over 12 inches of select granular material and 12 inches of an approved, compacted subgrade. Figure 3 of Appendix A illustrates the proposed roadway section. All remaining residential streets within the project are proposed to be reconstructed to the City's current standard of 32 feet in width, as measured from back -to -back of curb. As many of the roadways currently exist as 31 -foot or 33 -foot roadway sections, any proposed changes to the roadway widths should not adversely impact adjacent property owners. All existing storm sewer structures will also be evaluated on an individual basis during the final design of the project to determine if the location of the existing structures will allow for the roads to be modified to the meet City's current 32- foot -wide design standard. In many cases, reducing the roadway widths to meet the City's current design standard of 32 feet will reduce the street reconstruction costs associated with this project, as well as reduce the long -term maintenance costs associated with these roadways. Local residential streets within the project area will be re- established to include a 6 -inch crown, further promoting drainage within the roadway. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 11 All of the collector roadways within the project, including Flagstaff Avenue, Foliage Avenue, 164 Street /Finch Way /162 Street, and Fairgreen Avenue, will be reclaimed and reconstructed to the City's collector roadway design standard, and are proposed to consist of the following minimum section: 2 inches of bituminous wearing course, 2 inches of bituminous base course, and 6 inches of reclaimed aggregate base over 12 inches of an acceptable, compacted subgrade. 170 Street, which is also classified as a collector roadway by the City's Transportation Plan, will be constructed with 12 inches of select granular borrow material atop 12 inches of an approved, compacted subgrade, similar to the local residential streets within Cedar Highlands 1 St and 5 th Additions, in addition to the aforementioned collector roadway section. Figures 4 and 5 of Appendix A illustrate these proposed collector roadway sections, and Figure 6 of Appendix A illustrates the proposed roadway section for 170 Street. Additional pavement analysis for the collector roadways will be completed with the final design of the project. Collector roadways within the project area will be reconstructed to match the existing roadway widths, which currently vary from 40- to 44 -foot (as measured from face -to -face of curb). With the exception of those streets within Niakwa Village 2 nd Addition, all existing concrete curb and gutter within the project area is proposed to be completely removed and replaced in -kind. This means that barrier style curb will be reinstalled along Flagstaff Avenue and Foliage Avenue, and surmountable curb will be installed along all other collector roadways. As the majority of the existing concrete curb and gutter within Niakwa Village 2 nd Addition (Flagstaff Court North and Flagstaff Court South) is still in acceptable condition, only spot curb and gutter replacement is proposed within that portion of the project. All existing pedestrian curb ramps within the project area will be brought up to current ADA accessibility design standards as a part of the 2014 Street Reconstruction Project. 2.4.1.1 Flagstaff Avenue Traffic Calming Due to on -going resident concerns regarding traffic volumes and vehicle speeds along that portion of Flagstaff Avenue within the project area, it is proposed that additional driver feedback signs and the construction of traffic calming nodes (curb bumpouts) be installed in conjunction with the 2014 Street Reconstruction Project. Traffic calming nodes, or bumpouts, are proposed at all street intersections along Flagstaff Avenue including: Flagstaff Way, 164 Street /Gerdine Path, 163 Street, and Flagstaff Court and at each of the four proposed driver feedback sign locations. Construction of the nodes will narrow the travel lanes and the perceived overall roadway width, which has proven effective in reducing average vehicle speeds. Strategically locating these bumpouts will also allow area residents to continue to use Flagstaff Avenue for on- street parking, as the roadway will be striped to define parking areas outside of bumpout locations. These bumpouts will also serve as a means to shorten the Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 12 crosswalk distance for pedestrians at the intersection of Gerdine Path /164 Street and Flagstaff Avenue. Bumpouts installed at intersections will be restored with concrete, while the midblock bumpouts (i.e. the driver feedback sign locations) will be restored with sod. The proposed bumpouts will be designed to accommodate driver feedback signs along Flagstaff Avenue. The two existing driver feedback signs along Flagstaff Avenue, which were installed in 2012, will be permanently relocated to a proposed bumpout area adjacent to their current boulevard locations. In addition, two new driver feedback signs are proposed to be installed along Flagstaff Avenue with the 2014 Street Reconstruction Project. One driver feedback sign will serve southbound traffic along Flagstaff Avenue, and will be located between Gerdine Path and Dodd Boulevard (CSAH 9). The second driver feedback sign will serve northbound traffic along Flagstaff Avenue, and will be located between 164 Street / Gerdine Path and 160 Street (CSAH 46). Graphic renderings of the traffic calming bumpouts can be seen in Figures 7.1 and 7.2 of Appendix A. In response to resident feedback received at the October 1, 2013, neighborhood meeting to discuss the Flagstaff Avenue traffic calming improvements, analysis of that area north of 163 Street to accommodate additional bumpouts will be completed with final design of the project. 2.4.1.2 Sidewalk Improvements In response to requests received at the August 13, 2013, neighborhood meeting for the project, the existing concrete sidewalk along the south side of 170 Street, which currently extends between Cedar Avenue (CSAH 23) and the easterly intersection with Georgetown Way, is proposed to be extended to Gerdine Path to provide a connection to other sidewalk systems in the area. While this sidewalk extension is proposed wholly within the public right -of -way, additional communication with adjacent impacted property owners will be necessary in order to complete the sidewalk extension as proposed. All existing pedestrian curb ramps within the project area will be reconstructed to current ADA accessibility design standards. At both the August 13, 2013, and the October 1, 2013, neighborhood meetings to discuss the project, there were requests from residents to increase the width of the existing 48 -inch concrete sidewalks along both sides of Flagstaff Avenue, between 160 Street (CSAH 46) and Dodd Boulevard (CSAH 9), to 60 inches. The sidewalks along Flagstaff Avenue are maintained by the City during the winter months due to the proximity of the sidewalks to Parkview Elementary. The width of the smallest commercial equipment manufactured to clear snow from these sidewalks is 50 inches, which results in some level of sod damage every year from plowing activities. While the City does repair any sod damaged with sidewalk plowing operations, it is a source of frustration for residents along this stretch of Flagstaff Avenue and an annual maintenance expense for the City. With the street and bumpout improvements proposed for Flagstaff Avenue, it is also proposed to replace the existing 48 -inch concrete sidewalk with 60- inch -wide Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 13 concrete sidewalk. As these improvements will reduce the on -going maintenance costs associated with the repair of the boulevard sod adjacent to the sidewalk, the costs associated with widening the sidewalk along this stretch of Flagstaff Avenue will be funded by City Street Funds. Special Assessments to benefitting properties are proposed to fund 40% of the surface improvements identified for the project (with the exception of the Flagstaff Avenue sidewalk widening, which will be funded using City Street Funds), with the remaining 60% funded using City Street and Utility Funds. For properties along 170 Street, Georgetown Way, and Georgetown Court within Cedar Highlands 5 th Addition, where the corrosivity of the soils and utility replacement needs are providing the sole impetus to completely reconstruct the streets, the benefitting property owners adjacent to these improvements will only be assessed those costs associated with the surface improvements and not the complete reconstruction of the street, which will be funded in -part by the City's Utility Funds. 2.4.2 Storm Sewer Reconstruction of the streets also provides a timely opportunity to improve drainage conditions and increase the longevity of the streets within the project area by installing additional storm sewer facilities. Potential drainage improvements to be evaluated with final design of the project include: supplementing existing storm sewer facilities with the installation of additional catch basins throughout the project area, draintile installation in areas with poorly draining soils, and replacement of damaged or deteriorated infrastructure. While many properties are already connected to the City's public draintile system within Cedar Highlands 5 th Addition, residents within Cedar Highlands l s ' Addition, along Garcia Way and 170 Court, have indicated that they have private draintile facilities that daylight near the street. As a part of the proposed 2014 Street Reconstruction Project, a new draintile system and services will be installed for each lot along Garcia Way and 170 Court, and the existing draintile system and services will be replaced throughout the Cedar Highlands 5 th Addition Neighborhood in order to accommodate the proposed water main replacement work. Manholes, manhole castings, and catch basin castings are also proposed to be repaired /replaced to meet current City storm sewer standards as a part of the 2014 Street Reconstruction Project. Special Assessments to benefitting properties are proposed to fund 40% of the storm sewer improvements identified for the project with the remaining 60% funded using City Street and Utility Funds. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 14 2.4.3 Water Main Improvements The geotechnical investigation performed by Braun Intertec in October 2013 included the collection of soil samples from within the 2014 Street Reconstruction Project area to measure the corrosivity of the soils within select areas of the project. The results of the corrosivity testing indicate the project area does contain some corrosive soils that impact iron water main pipe. Corrosive soils were discovered throughout Cedar Highlands 1st and 5 th Additions. It is proposed that in conjunction with the street improvements identified for 2014, the existing water main be replaced with pipe not susceptible to corrosive soils along the following streets due to the corrosive nature of the soils: ■ Garcia Way ■ 170 Street • 170 Court ■ Georgetown Way ■ Georgetown Court Replacing the existing water main facilities in these areas of the 2014 Street Reconstruction Project provides a timely and cost - effective solution to what has been a long -term maintenance issue within the area. It is proposed that the existing cast iron and ductile iron water main facilities within the Cedar Highlands Neighborhood be replaced with PVC water main pipe to withstand the corrosive nature of the soils, reducing the potential for future water main repairs in the area. Additionally, there has been a concentrated water main break history along Flagstaff Avenue, between Dodd Boulevard (CSAH 9) and Flagstaff Way. While the soils were not determined to be corrosive in this area of the project, it is proposed to replace the existing cast iron water main with ductile iron pipe due to the recent break history. Figure I of Appendix A illustrates the proposed water main replacement locations within the project area. Valves and water main bolts will also be replaced within the project area as determined by the Public Works Department's 2013 evaluation of the system. Special Assessments to benefitting properties are proposed to fund 40% of the surface water main improvements (i.e. new valve boxes and valve box adjustments) with the remaining water main costs funded using City Utility Funds. 2.4.4 Sanitary Sewer Improvements Nearly all of the 146 sanitary sewer manholes within the project area were identified as needing new rings and /or castings, and will be repaired as a part of this project. Additionally, all sanitary sewer manholes within the street reconstruction area will receive external chimney seals as a part of the project to reduce the potential for inflow and infiltration (I & I) issues and reduce the frequency Of maintenance repairs. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 15 The proposed improvements are considered routine maintenance, and therefore, the costs associated with the sanitary sewer manhole ring /casting replacements are included in the surface improvement costs, which are proposed to be funded using a combination of Special Assessments to benefitting property owners (40 %) and City Funds (60 %). 2.4.5 Street Sign Replacement All existing street signs within the project will be replaced with new street signs that meet the Federal Highway Administration's (FHWA) requirements for retro- reflectivity. Special Assessments to benefitting properties are proposed to fund 40% of the street sign improvements identified for the project with the remaining 60% funded using City Street Funds. 2.4.6 Mailbox Replacement Where curb and gutter replacement is proposed, it is the City's intent to salvage and reinstall the existing mailboxes and mailbox supports that may be impacted with construction. In the event the condition of the existing mailbox support warrants replacement prior to reinstallation, the City is proposing to salvage the existing mailbox and install a new mailbox support that will meet both City Standards and United States Postal Service (USPS) requirements. Special Assessments to benefitting properties are proposed to fund 40% of the mailbox improvements identified for the project with the remaining 60% funded using City Street Funds. 2.4.7 Permits /Approvals An NPDES permit for construction activity will be required since more than one (1) acre will be disturbed by construction activities with the project. A permit from the Minnesota Department of Health (MDH) will also be required for the replacement of water main facilities within the Cedar Highlands Neighborhood. A Dakota County Work in Right -of -Way permit will be required for any work within County rights -of -way, including: Cedar Avenue (CSAH 23), Dodd Boulevard (CSAH 9), and 160 Street (CSAH 46). 2.4.8 Construction Access /Staging The contractor will be responsible for providing access to all properties throughout the project. Adequately signed detours will be identified to direct traffic around the construction zones and notify users of the increased truck and construction activity. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 16 Construction will be phased so as to reconstruct the streets located at the center of the project first, such that construction truck traffic will not need to access newly reconstructed streets to complete the project. Detailed construction phasing plans will be developed with final design of the project. 2.4.9 Public Involvement Two public informational meetings were held for the project to discuss the proposed improvements. The first neighborhood meeting was conducted on August 13, 2013, for all property owners within the proposed project area. The second neighborhood meeting was conducted on October 1, 2013, for property owners along Flagstaff Avenue to discuss potential traffic calming opportunities along that roadway. Preliminary information was presented to approximately 120 attendees at the first neighborhood meeting and approximately 20 attendees at the Flagstaff Avenue neighborhood meeting and included information regarding the proposed improvements, costs, funding, schedule, and impacts associated with the project. Comment cards were made available to attendees at the meetings. Summaries of the correspondence received and questions and answers provided at the informational meetings are included in Appendix E. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 17 3. FINANCING 3.1 Opinion of Cost Detailed opinions of cost for the various project areas can be found in Appendix B of this report. The opinions of cost incorporate estimated 2014 construction costs and include a 6.5% contingency factor. Indirect costs are projected at 28% of the construction cost and include engineering, legal, financing, and administrative costs. Table 2 below provides a summary of the opinions of probable cost for the 2014 Street Reconstruction Project. 3.2 Funding Financing for the 2014 Street Reconstruction Project will come from City Funds and Special Assessments. The water main repairs are proposed to be financed by the City's Water Operating Fund. The sanitary sewer repairs are proposed to be financed by the City's Sanitary Sewer Operating Fund. Special Assessments to benefitting properties are proposed to fund 40% of the roadway surface and storm sewer improvements identified to be reconstructed for the project, with the remaining 60% funded using City Funds. Special Assessments to benefitting properties along 170 Street, Georgetown Way, and Georgetown Court are proposed to fund 40% of the surface improvements identified within this area of the project. The City's Water Operating Fund will fund those street improvements driven by the water system improvements in this area. Assessments for this project were calculated on a per parcel (unit) basis as identified in the City's Assessment Policy. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 18 Table 2 — 2014 Street Improvement Project Summary of Cost Schedule Amount Schedule A — Surface Improvements $6,467,180 Schedule B — Sanitary Sewer Improvements $84,620 Schedule C — Water Main Improvements $1,948,990 Schedule D — Storm Sewer Improvements $1,511,350 Schedule E — Pedestrian Improvements — Flagstaff Avenue $223,910 TOTAL $10,236,050 3.2 Funding Financing for the 2014 Street Reconstruction Project will come from City Funds and Special Assessments. The water main repairs are proposed to be financed by the City's Water Operating Fund. The sanitary sewer repairs are proposed to be financed by the City's Sanitary Sewer Operating Fund. Special Assessments to benefitting properties are proposed to fund 40% of the roadway surface and storm sewer improvements identified to be reconstructed for the project, with the remaining 60% funded using City Funds. Special Assessments to benefitting properties along 170 Street, Georgetown Way, and Georgetown Court are proposed to fund 40% of the surface improvements identified within this area of the project. The City's Water Operating Fund will fund those street improvements driven by the water system improvements in this area. Assessments for this project were calculated on a per parcel (unit) basis as identified in the City's Assessment Policy. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 18 The funding level anticipated through the levy of Special Assessments to benefitting property owners for street improvements is $3,055,350 with the following proposed assessments: Valley Park 3 rd 5 th 7th and 8 th Additions; Sunrise Village; Dodd Pointe 1 St 2 and 3 rd Additions; and Cedar Highlands lst Addition Single Family Unit Assessment Rate .... ............................... $4,471.51 per unit Cedar Highlands 5 th Addition Single Family Unit Assessment Rate ...... $1,924.26 per unit Niakwa Village 2 nd Addition Single Family Unit Assessment Rate........ $2,166.96 per unit The proposed assessment roll is included in Appendix C of this report, along with an Assessment Map ID highlighting the benefitting properties and the assessment calculations for benefitting property owners. Table 3 — 2014 Street Improvement Project Funding Summary Funding Source Amount Street and Storm Sewer Assessments $3,055,350 City Water Funds $1,948,990 City Sanitary Sewer Funds $84,630 City CIP Funds $5,147,080 TOTAL $10,236,050 Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 19 4. PROJECT SCHEDULE The proposed project schedule for the 2014 Street Reconstruction Project is as follows Neighborhood Open House ................ ............................... ......................... August 13, 2013 Order Feasibility Report .............................................. ............................... August 19, 2013 Flagstaff Avenue Neighborhood Open House ..................... ........................October 1, 2013 Accept Feasibility Report /Set Public Hearing ................... ........................October 21, 2013 Public Hearing /Order Project /Authorize Ad for Bids ..... .......................November 18, 2013 Open Bids /Compute Assessments .................................. ............................... March 6, 2014 Declare Costs /Set Assessment Hearing ........................ ............................... March 17, 2014 Assessment Hearing ........................................................ ............................... April 21, 2014 Award Construction Contract ......................................... ............................... April 21, 2014 Begin Construction* .............................................................. ............................... May 2014 Substantial Completion ... .............................................................. October/November 2014 Certify Assessments to County ..................................... ............................... December 2014 * Schedule assumes any necessary private utility work is completed prior to start of construction. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 20 5. FEASIBILITY AND RECOMMENDATION The 2014 Street Reconstruction Project includes roadway reclamation, street reconstruction, and water main improvements along Garcia Way West, 170 Street West, 170 Court West cul -de- sac, Georgetown Way, Georgetown Way cul -de -sac, Georgetown Court, Excelsior Drive, Excelsior Court, Excelsior Circle, Dodd Lane, Excel Way, Foliage Avenue, 169 Street West, Lower 169 Street West, Flounder Court, Flounder Avenue West, Flagstaff Avenue, 163 Street West, Fishing Avenue West, Lower 161 Street West, Finland Avenue West, Fishing Way West, 161 Street West, Finch Avenue West, 164 Street West /Finch Way West /162 Street West, Fairgreen Avenue, Fernando Way, Fernando Way cul -de -sac, Flagstaff Way, Finesse Way, Fantasia Avenue, Flagstaff Court North, and Flagstaff Court South. Complete curb and gutter replacement and spot sidewalk replacements will be made within the Cedar Highlands, Valley Park, and Dodd Pointe areas of the project. The sidewalk along the south side of 170 Street will be extended from Georgetown Way to Gerdine Path, and the existing 48 -inch sidewalk along Flagstaff Avenue will be replaced with 60 -inch sidewalk as a part of the project. Spot repair and replacement of structurally deficient curb will be completed within the Niakwa Village Neighborhood. Structurally deficient storm and sanitary sewer manholes and water main valves identified by the City's Public Works Department will also be replaced as a part of this proj ect. The total estimated cost for the 2014 Street Reconstruction Project including roadway, sidewalk, storm sewer, sanitary sewer, and water main improvements is $10,236,050. Proposed funding for the project is provided through a combination of Special Assessments and City Funds. This project is feasible, necessary, and cost - effective from an engineering standpoint. The project feasibility is subject to financial review by the City. Based on the information contained in this report, it is recommended to proceed with the improvements as outlined in this report. Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Page 21 APPENDIX A Figure 1: Location Map Figure 2: Typical Section — Residential Streets Figure 3: Typical Section — Residential Streets — Cedar Highlands Figure 4: Typical Section — Collector Streets —164 Street /Finch Way /162 Street and Fairgreen Avenue Figure 5: Typical Section — Collector Streets — Foliage Avenue and Flagstaff Avenue Figure 6: Typical Section — Collector Streets —170 Street Figure 7: Concept Flagstaff Avenue Improvements Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 R/W R/W 30' 5' �' Mqx 2.0% 4.07 - 1 MAX CONCRETE SIDEWALK (VARIES 48" - 60 ' INSET A 5' NOTE: 6" CROWN (MEASURED FROM FLOWLINE) MPX � 3.125 3.125 %, 4; 6" MIN. TOPSOIL AND SOD ON ALL DISTURBED AREAS BEHIND CURB 30' 32' B -B INSET A 1.5" TYPE SP 12.5 WEAR COURSE MIX (2,C) (SPWEB240C) 2357 BITUMINOUS TACK COAT 2.0" TYPE SP 12.5 NON WEAR COURSE MIX (2,C) (SPNW6230C) 6" MINIMUM RECLAIMED AGGREGATE BASE APPROVED SUBGRADE (12" MINIMUM DEPTH) D CONCRETE CURB AND GUTTER % � :4 M • 1 K: \02109- 391 \Cad \Exhibits \FIG 02.dwg, SECTION R/W R/W 30' 30' 5' 1 ' 4 MqX 2.0% 4.0% 32' B -B NOTE: 6" CROWN (MEASURED FROM FLOWLINE) � 3.125 3 .125 %, 5' D412 CONCRETE CURB AND GUTTER 1:4 M 0 CONCRETE SIDEWALK 1 (48" WIDTH) 6" PERF PVC PIPE DRAIN INSET A r►RAON r_1 6" MIN. TOPSOIL AND SOD ON ALL DISTURBED AREAS BEHIND CURB 1.5" TYPE SP 12.5 WEAR COURSE MIX (2,C) (SPWEB240C) 2357 BITUMINOUS TACK COAT 2.0" TYPE SP 12.5 NONWEAR COURSE MIX (2,C) (SPNWB230C) 6" MINIMUM RECLAIMED AGGREGATE BASE 12" MINIMUM SELECT GRANULAR MODIFIED MATERIAL APPROVED SUBGRADE (12" MINIMUM DEPTH) K: \02109- 391 \Cad \Exhibits \FIG 03.dwg, SECTION R/W R/W 40' 5' �' Mqk 2.0% 4.07 - CONCRETE SIDEWALK (48" WIDTH) INSET A - 44' F -F 5' NOTE: 6" CROWN (MEASURED FROM FLOWLINE) MPX � 2.0% 2.0% :4 M 6" MIN. TOPSOIL AND SOD ON ALL DISTURBED AREAS BEHIND CURB 40' 40' INSET A 2.0" TYPE SP 12.5 WEAR COURSE MIX (2,C) (SPWEB240C) 2357 BITUMINOUS TACK COAT 2.0" TYPE SP 12.5 NON WEAR COURSE MIX (2,C) (SPNW6230C) 6" MINIMUM RECLAIMED AGGREGATE BASE APPROVED SUBGRADE (12" MINIMUM DEPTH) D412 CONCRETE CURB AND GUTTER 4�% � • 1 K: \02109- 391 \Cad \Exhibits \FIG 0 4.dwg, SECTION R/W R/W 40' - 55' 40' - 55' 5' 1 ' 4 Mqx 2.0% 14.0% _� 4 MAX 41 CONCRETE SIDEWALK (60" PROPOSED WIDTH) r►RAON r_1 40' F -F 5' Fl B618 CONCRETE CURB AND GUTTER 4.0% 1 ..4 MPX �- 2.0% 2,0% �- 7 : 4 MAX INSET A 6" MIN. TOPSOIL AND SOD ON ALL DISTURBED AREAS BEHIND CURB 2.0" TYPE SP 12.5 WEAR COURSE MIX (2,C) (SPWEB240C) 2357 BITUMINOUS TACK COAT 2.0" TYPE SP 12.5 NONWEAR COURSE MIX (2,C) (SPNWB230C) 6" MINIMUM RECLAIMED AGGREGATE BASE APPROVED SUBGRADE (12" MINIMUM DEPTH) K: \02109- 391 \Cad \Exhibits \FIG US.dwg, SECTION R/W R/W 30' 5' �' Mqx 2.0% 4.07 - 1 MAX CONCRETE SIDEWALK (48" WIDTH) - 44' B -B 5' NOTE: 6" CROWN (MEASURED FROM FLOWLINE) MPX � 3.125 3 .125 %, :4 M 6" MIN. TOPSOIL AND SOD ON ALL DISTURBED AREAS BEHIND CURB 32' 30' INSET A 2.0" TYPE SP 12.5 WEAR COURSE MIX (2,C) (SPWEB240C) 2357 BITUMINOUS TACK COAT 2.0" TYPE SP 12.5 NON WEAR COURSE MIX (2,C) (SPNW6230C) 6" MINIMUM RECLAIMED AGGREGATE BASE 12" MINIMUM SELECT GRANULAR MATERIAL APPROVED SUBGRADE (12" MINIMUM DEPTH) INSET A D412 CONCRETE CURB AND GUTTER 4�% � • 1 K: \02109- 391 \Cad \Exhibits \FIG Uti.dwg, SECTION HRU LANE �NS9 N 0 21 09 39 0 FIGURE 7.1 to �qo 2014 STREET W � Mi�adie, n;rveoaFe m RECONSTRUCTION PROJECT SB .wce s.eo FLAGSTAFF AVENUE IMPROVEMENTS -/ �NS9 N 0 21 09 39 0 FIGURE 7.2 qo 2014 STREET ,�� e 1, Mira die, n;rvo�aFe RECONSTRUCTION PROJECT SB .wce s.eo FLAGSTAFF AVENUE IMPROVEMENTS -/ APPENDIX B Opinion of Probable Cost Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Opinion of Probable Cost WSBProject 2014 Street Reconstruction Project Design By: KAK ProjectLocation: City of Lakeville Checked By: MRH City PrjectNo.: tl14 -02 WSBProjectNo: 2199 -391 Date, 10/21/2013 Item No. MN/DOT Specification No. Description Unit Bid Unit Price Total Project 2014 Street Reconstruction Project Funding Source Street Improvement Fund and Special Assessments Water Main Feed Sanitary Server Fund Estimated Total Quantity Estimated Total Cost Estimated Total Quantity Estimated Total Cost Estimated Total Quantity Estimated Total Coat A. Surface Improvements 1 2021501 MOBILIZATION LUMPSUM $226,00000 1 $226,00000 1 $226,00000 0 1000 0 $000 2 2101501 REMOVE CON CRETE VALLEY GUTTER LIN FT $400 150 $60000 150 $60000 0 $000 0 $000 3 2101502 CLEARING TREE $22500 366 $8235000 301 $6]]2500 65 $1462500 0 $000 4 2101507 GRUBBING TREE $22500 366 $8235000 301 $67]2500 65 $14;62500 0 $000 5 2101511 CLEARING& GRUBBING - SHRUB EACH $10000 10 $100000 9 $90000 1 $10000 0 $000 6 2101603 ROOT CUTTING LIN FT $400 170 $68000 70 $280:00 too $400D 0 $000 7 2104501 REMOVE& REPLACE CON CRETE CU RB& G UTTER LIN FT $1000 78,870 $788,70000 71,780 $71780000 7DW $70,90000 0 $000 8 2104503 REMOVE CONCRETE WALK SOFT $150 39,900 $5985000 1 20,500 $30,75000 1 19,400 $2910000 0 $000 9 2104503 REMOVE BITUMINOUS WALK SOFT $150 1230 $184500 1,150 $172500 80 $12000 0 $000 10 2104505 REMOVE CONCRETE DRIVEWAY PAVEMENT SO YD $800 2,240 $1792000 2020 $16,16000 220 $176000 0 $000 11 21N 505 REMOVE BITUMINOUS DRNEWAYPAVEMENT SO YD $300 14220 $42,66000 12,940 $38,82000 1,280 $3,34000 0 $0.00 12 2104509 REMOVE SIGN EACH $2500 147 $3,67500 147 $367500 0 $000 0 $000 13 2104509 REMOVE MAILBOX SUPPORT EACH $1000 58 $58000 53 $53000 5 $5000 0 $0.00 14 21N 509 REMOVE MAILBOX EACH $1500 10 $15000 9 $13500 1 $1500 0 $000 15 21N 511 SAWING CO NCRETE PAVEMENT (TO LL DEPTH) LIN FT $350 7,200 $25,20000 7010 $2453500 190 $66500 0 $000 16 2104513 SAWING BITUMINOUS PAVEM ENT (FULL DEPTH) LIN FT $250 14,670 $36,67500 13,440 $33,600.00 1,230 $3,07500 0 $0.00 17 2104601 SALVAGE AND REINSTALL LANDSCAPE STRUCTURES LUMP SUM $25,00000 1 $25,00000 1 $22,25000 0 $2,75000 0 $000 18 2104602 SALVAGE AND REINSTALL MAIL B OX EACH $5000 753 $3],650.00 691 $34,55000 62 $3,10000 0 $000 19 2105501 COMMON EXCAVATION CU YO $1200 12,250 $147,00000 1050 $12,60000 11,200 $134400.00 0 $000 20 2105507 SUBGRADE EXCAVATION CU YD $1100 1,160 $12,76000 160 $176000 1,000 $1100000 0 1 $0.00 21 2105522 SELECT GRAND FAR BORROW (CV) CU YD $800 8,300 $66,400 00 0 $000 8300 $66,400.00 0 $000 22 2105525 TOPSOIL BORROW CU YD $1500 760 $11,40000 750 $1125000 10 $15000 0 $000 23 2504602 DEWATERING EACH $10,00000 1 $1000000 0 $000 1 $1000000 0 $000 24 25N 602 GEOTENULE FABRICTYPE V EACH $125 4,800 $6,00000 0 1 $000 4,800 soiaw00 0 $000 25 2105607 112 "CLEAR ROCK CU YD $4000 100 $4,00000 100 $4,00000 0 $000 0 $000 26 2112501 SUBGRADE PREPARATION ROAD STA $17500 427 $74,72500 381 $66,67500 46 $8,05000 0 $000 27 2123610 STREET SWEEPER (WITH PICKUP BROOM) HOUR $12500 160 $20,00000 160 $20,00000 0 $000 0 $0.00 28 2130501 WATER MGAL $3000 1,150 $34,50000 1,050 $3150000 100 $3,00000 0 $000 29 2131502 CALCIUM CHLORIDE GALLONS $125 5,000 $6,25000 4,200 $5,25000 800 $1,00000 0 $000 30 2211501 AGGREGATE BASE CLASS 5 TON $1000 580 $5,80000 510 $5,10000 70 $70000 0 $000 31 2232501 MILL BITUMINOUS STEP JOINT (15 ") LIN FT $600 1,450 $8,70000 1,300 $],80000 150 $90000 0 $0.00 32 2331604 BITUMINOUS PAVEMENT RECLAMATION SO YD $150 149,800 $22470000 149,800 $224,700.00 0 $000 0 $0.00 33 2357502 BRO MIN GO S MATERIAL FOR TACK COAT GALLONS $300 8,070 $24,21000 8,070 $24,21000 0 $000 0 $000 34 2360501 TYPE SP 125 WEARIN G COO RSE M IX (2,G) TON $5400 15,300 $82620000 15,300 $826,200.00 0 $000 0 $0.00 35 2360502 TYPE SP 125 N ON WEAR CO URSE MIX C,C) TON $5200 18,400 $95680000 16,400 $852,80000 2000 $104000.00 0 $000 36 2360503 TYPE SP 95 WEARING CO URSE MIX (2,B) 30 " THICK BOYD $2300 14,420 $33166000 13,140 $30222000 1,280 $29,44000 0 $000 37 2505601 UTILITY COORDINATION LUMP SUM $1500000 1 $15,00000 1 $15,00000 0 $000 0 $000 38 2506522 ADJU ST FRAME& RIN G CASTIN G(SAN ITARY) EACH $50000 106 $53,00000 106 $53,00000 0 $000 0 $000 39 2506522 ADJU ST FRAME& GIN G CAST ING(STORM) EACH $50000 65 $32,50000 1 65 $32,50000 0 $000 0 $000 40 2506522 ADJU ST FRAME &RING CASTING (WATER) EACH $50000 1 $500.00 1 $50000 0 $000 0 $000 41 2521501 25" BITUM IN OUS WALK SOFT $500 1,230 $6,15000 1,750 $5,75000 80 $40000 0 $000 42 2521501 4 "CONCRETEWALK SOFT $400 47400 $189,60000 28,000 $112,00000 19,400 $]],60000 0 $000 Opinion of Probable Cost WSBProject 2014 Street Reconstruction Project Design BY: KAK ProjectLocation: City of Lakeville Checked By: MRH City PrjectNo.: tl14 -02 WSBProjectNo: 2109 -391 Date, 10/21/2013 Item No. MN/DOT Specification No. Description Unit Bid Unit Price Total Project 2014 Street Reconstruction Project Funding Source Street Improvement Fund and Special Assessments Water Main Feed Sanitary Server Fund Estimated Tmet Quantity Estimated Total Cost Estimated Total Quantity Estimated Total Cost Estimated Total Quantity Estimated Total Cost 43 2531507 7" CONCRETE DRIVEWAY PAVEM ENT SO YD $5000 2,240 $112,00000 2020 $10100000 220 $1 Tom 00 0 $000 44 2531602 PEDESTRIAN CURB RAMP EACH $45000 65 $29,250.00 65 $24,25000 0 $000 0 $000 45 2531604 7 "CONCRETEVALLEYGUTTER SO YD $6500 200 $13,000.00 200 $13,00000 0 $000 0 $000 46 2531618 TRUNCATED DOMES SOFT $4000 585 $23,40000 585 $23,40000 0 $000 0 $000 47 2540.602 INSTALL MAIL BOX SUPPORT EACH $2500 57 $142500 52 $130000 5 $12500 0 $000 48 2540602 MAILBOX EACH $2500 12 $30000 11 $27500 1 $2500 0 $000 49 2540602 MAIL BOX SUPPORT EACH $10000 57 $5,70000 52 $5,20000 5 $50000 0 $000 50 2540602 MAIL BOX (TEMPORARY) EACH $2000 753 1 $15,06000 691 $13,82000 62 $124000 0 $o.00 51 2545602 ELECTRICAL SERVICE LUMP SUM $30,00000 1 $30,00000 1 $30,00000 0 $000 0 $000 52 2557602 REPAIR DOG FENCE EACH $15000 56 $8,400:00 51 $765000 5 $75000 0 $000 53 2563601 TRAFFIC CONTROL LUMP SUM $25,00000 1 $25,00000 1 $25,000.00 0 $000 0 $0.00 54 2564531 SIGN PANELSTYPE C &D LUMP SUM $17,00000 1 $17,00000 1 $17,00000 0 $000 0 $000 55 2565601 DRIVER FEEDBACK SIGN EACH $1000000 2 $2000ODD 2 $20,00000 0 $000 0 $000 56 2565601 RELOCATE DRIVER FEEDBACK SIGN EACH $250000 2 $5,00000 1 2 $5,00000 0 $000 0 $000 57 2573502 SILT FEN CE, TYPE MACH INE SLICED LIN FT $200 2,350 $4,70000 2050 $4,100.00 300 $60000 0 $000 58 2573 540 FILTER LOG TYPE WOOD FIBER BIOROLL LIN FT $3 Do 2,350 $7,05000 2050 $6,15000 300 $90000 0 $0.00 59 2573602 TEMPORARY ROCK CON STRUCTION ENTRAN CE EACH $50000 18 $9,000.00 16 $800000 2 $100000 0 $000 6D 2575505 SODDING TYPE LAWN(INCL. TOPSOIL &LETT_) SO YD $3.50 123,500 $43225000 103,400 $36190000 20,100 $70,35000 0 $000 61 2571501 CONIFEROUS TREE 8'HT. B &B TREE $40000 31 $1240000 0 $000 31 $12400.00 0 $000 62 2571502 DECIDUOUS TREE 25 " CAL B &B TREE $40000 29 $11600.00 0 $000 29 $1160000 0 $000 63 2582501 PAVEMENT MESSAGE(RT ARROW) - PAINT EACH $25000 1 $250.00 1 $25000 0 $000 0 $000 64 2582501 PAVEMENT MESSAGE ITT ARRO W) - PAINT EACH $25000 2 $50000 2 $50000 0 $000 0 $000 65 2582502 4" SOLID LINE WHITE - PAINT LIN FT $050 18,190 1 $9,09500 18,190 $9,09500 0 $000 0 $000 fib 2582502 4" DOUBLE SOLID LINE YELLOW - PAINT LIN FT $100 10,180 $10,78000 10180 $10,18000 0 $000 D $000 67 2582502 12" SOLID LINEWHITE -PAINT LIN FT $800 80 $64000 80 $64 000 0 $000 0 $000 fib 2582503 CROSSWALK MARKING- POLY PREFORM (GROUND IN) SOFT $15.00 870 $13,05000 870 $13,05000 0 $000 0 $000 fig COMMUNICATIONS SYSTEM UPGRADE LUMP SUM $25,000.00 1 $25,00000 1 $25,000.00 1 0 1 $000 0 $000 Schetlule A TOt.1- Sortace l mproveoI $5,341,990.00 $4,633,115.00 $701 $0.00 B. Sanitary Improvements 70 2021501 MOBILIZATION LUMP SUM $300000 1 $300000 0 $0.00 0 $000 1 $3,00000 71 2105602 EXCAVATETO LOCATE SANITARY SERVICE EACH $45000 10 $450000 0 $0.00 0 $000 10 $450000 72 2104501 REMOVE SANITARY SEWER SERVICE PIPE LIN FT $800 180 $1,44000 0 $000 0 $000 180 $144000 73 25M 511 4 " PVC PIPE SEWER LIN FT $3200 180 $5]6000 0 $000 0 $000 180 $5,76000 74 2503602 CONNECTTO EXISTING SANITARY SEWER SERVICE EACH $28000 6 $168000 0 $000 0 $000 6 $168000 75 2503602 8 "X4 "PVC WYE EACH $65000 6 $390000 0 $000 0 $000 6 $3,90000 76 2503602 REMOVE CASTING ASSEMBLY EACH $16300 64 $10,43200 64 $1043200 0 $000 0 $000 77 25M 602 CHIMNEY SEALS EACH $20000 176 $35,20000 0 $000 0 $000 176 $3520000 78 25W 602 RECONSTRUCT SANITARY MANHOLES EACH $110000 6 $660000 0 $000 0 $000 6 $660000 79 2506602 CASTING ASSEMBLY (SAN LARY) EACH $800.00 64 $5120000 64 $51,20000 0 $000 0 $0.00 Sch.d.le B Total - Sanitary Improvements $123,712.00 $61,63200 $0.001 $62,080.00 C. Water Main Improvements 80 1 2021501 1 MOBILIZATION JILUMPSUMI $68,100001 1 1 $68,10000 0 1 $0.00 1 1 $68,10000 0 $0.00 Opinion of Probable Cost WSBProject 2014 Street Reconstruction Project Design By: KAK ProjectLocation: City of Lakeville Checked By: MRH City ProjectNo.: tl14 -02 WSBProjectNo: 2109 -391 Date. 10/21/2013 Item No. MN/DOT Specification No. Description Unit Bid Unit Price Total Project 2014 Street Reconstruction Project Funding Source Street Improvement Fund and Special Assessments Water Main Feed .Sanitary.Selver Fund Estimated Total Quantity Estimated Total Cost Estimated Total Quantity Estimated Total Cost Estimated Total Quantity Estimated Total Cost 81 21N 509 REMOVE WATER SERVICE PIPE EACH $125 3120 $390000 0 $000 3,120 $3900.00 0 $060 82 21N 509 REMOVEWATER MAIN EACH $460 M20 $25,68060 0 $000 6,420 $25,68000 0 $060 83 2451609 REMOVE GATE VALVE AND BOX TON $15060 18 $2,70000 0 $000 18 $2,]00.00 0 $000 84 2504601 REMOVE CURB STOP AND BOX EACH $5560 99 $544500 0 $0.00 99 $5,44500 0 $060 85 25N 602 REMOVE HYDRANT EACH $30060 20 $680000 0 $0.00 20 $6,00000 0 $060 86 2451 609 GRANULAR FOUNDATION AND /OR BEDDING TON $860 200 $1,600 00 0 $000 200 $1,60010 0 $060 87 25N 601 TEMPORARY WATER SERVICE LUMP SUM $4080000 1 $40,000.00 0 $000 1 $40,00000 0 $060 88 25N 602 CON N ECT TO EXISTING WATER MAIN EACH $180000 9 $980000 0 $000 9 $9,00000 0 $o.00 89 25N 602 CON N ECT TO EXISTIN G WATER SERVICE EACH $15060 99 $14 0 $000 99 $14850.00 0 $060 90 2504602 HYDRANT EACH $350000 20 $70,00000 0 $000 20 $7080000 0 $060 91 2504602 1 "CORPORATION STOP EACH $20060 99 $19,80060 0 $000 99 $19,800.00 0 $0.00 92 25N 602 6 "GATE VALVE AND BOX EACH $150000 20 $30,00060 0 $000 20 $30,00000 0 $000 93 2504602 8" GATE VALVE AND BOX EACH $780000 7 $12,60060 0 $000 7 $12,50060 0 $0.00 94 25N 602 12" GATE VALVE AND BOX EACH $2,75000 11 $30,25060 0 $000 1111 $30,250.00 0 $000 95 2504602 1 "CURB STOPAND BOX EACH $27500 99 $27,22560 0 $000 99 $27,22500 0 $0.00 96 2504602 REMOVE AN D REPLACE GATE VALVE TOP SECTION EACH $150 Do 34 $510000 34 $5,10060 0 $000 0 $060 97 25N 602 REMOVE AND REPLACE GATE VALVE BOLTS EACH $75000 10 $7,50000 10 $7,50060 0 $000 0 000 98 25N 602 ADJUST VALVE BOX EACH $30000 10 $380000 10 $3,00060 0 $000 0 $060 99 25N 602 ADJUST HYDRANT EACH $50000 11 $5,50000 11 $5,50060 0 $000 0 $060 100 25N 602 RECONSTRUCT VALVE BOX EACH $50060 13 $650000 0 $000 13 $6,50000 0 $060 101 25N 602 CURB BOX REPAIR EACH $50060 55 $27,50060 0 $000 55 $27,50060 0 $060 102 25N 602 ADJUST CURB BOX EACH $15000 55 $825000 55 $8,25060 0 $000 0 $000 103 2504602 IRRIGATION SYSTEM REPAIR EACH $30060 73 $2190060 66 $19,80000 7 $2,10000 0 $060 104 25N 603 1 "TYPE K COPPER PIPE $2060 3120 $62,40060 0 $000 3,120 $62,400.00 0 $060 105 2 504603 6 "WATER MAIN DUCTILEIRON CL52- POLYMAP $3260 150 $4,80000 0 $000 150 $4,80000 0 $060 106 25N 603 6 "WATER MAIN DUCTILEIRON CL52 $3260 60 $192000 0 $000 60 $192000 0 $000 107 25N 603 12 "WATER MAIN DUCTILE IRON CL 52 $6560 400 $2600000 0 $000 400 $26,00000 0 $000 108 25N 603 8" WATER MAIN - PVC C900 3LINH$2 $2560 3410 $85,250 00 0 $0 00 3 410 $85,250 00 0 $060 109 25N 603 12" WATER MAIN -PVC C900 $3260 2510 $80,320 00 0 $000 2,510 $80,32000 0 W 00 110 22N Lot 4 "POLYSTVRENEINSULATION $4060 200 $880000 0 $000 200 $8,00000 0 $060 111 2504608 DUCTILE IRON FBTINGS -EPDXY COATED $460 8530 $3412000 0 $000 8530 $34,12000 0 $0.00 112 2505601 UTILDYCOORDINATION 080000 1 $10,000.00 0 $000 1 $10,00000 0 $060 113 2563601 TRAFFIC CONTROL LUMP SUM $5.000.00 1 $5.000.00 0 $000 1 $5,00000 0 W00 Sch,d,le C Total - Water Main Improvements $770,210.00 $49,150.00 $721,050.00 $0.00 D. Storm Sewer Improvements 114 2104501 REMOVE SEWER PIPE (STORM) LIN FT $600 10620 $63,72060 10,620 $63,72000 0 $000 0 $060 115 2104501 REMOVE PVC DRAIN TILE LIN FT $260 2200 $440000 2,200 $440060 0 $000 0 $060 116 21N 509 REMOVE DRAINAGE STRUCTURE EACH $35000 89 $31,15060 89 $31,15000 0 $000 0 $000 117 2104509 REMOVE CASTING ASSEMBLY EACH $12500 29 $3;62500 29 $3,62500 0 $000 0 $060 118 21N 509 SALVAGE CASTING ASSEMBLY EACH $12500 30 $3,75000 30 $3,75000 0 $000 0 $060 119 25W 602 RECONSTRUCT DRAINAGE STRUCTURE EACH $65000 13 $8,45000 13 $8,450.00 0 $000 0 $o 60 120 DITCH EXCAVATION CU YD $10000 200 $20,00060 200 $20,00000 0 $000 0 $000 121 2502 521 6 "TP PIPE DRAIN CLEAN OUT EACH $15000 40 $680000 40 $6,0000o 0 $000 0 $0.00 Opinion of Probable Cost WSBProject 2014 Street Reconstruction Project Design By: KAK ProjectLocadon: City of Lakeville Checked By: MRH City PrjectNo.: tl14 -02 WSBProjectNo: 2109 -391 Date, 10/21/2013 Item No. MN/DOT Specification No. Description Unit Bid Unit Price Total Project 2014 Street Reconstruction Project Funding Source Street Improvement Fund and Special Assessments Water Main Feed Sanitary Server Fund Estimated Total Quantity Estimated Total Cost Estimated Total Quantity Estimated Total Cost Estimated Total Quantity Estimated Total Cost 122 2502 521 4 "TP PIPE DRAIN CLEAN OUT EACH $12500 94 $11,750 00 94 $11 750 DO 0 $000 0 $0 00 123 2502541 1 6" PERFO RATED TH F OPLASTIC(TP)DRAIN PIPE LIN FT $1300 11700 $152,10000 11,700 $152,100.00 D $000 0 $000 124 2502541 4 "(TP)PIPE DRAIN LIN FT $1100 1550 $17,05000 1550 $17,050 DO 0 $000 0 $000 125 2503 521 12" RC PIPE SEWER DESIGN 3006 CLASS V LIN FT $2600 1020 $26,52000 1,020 $26,520 00 0 $000 0 $000 126 2503 521 15" RC PIPE SEWER DESIGN 3006 CLASS V LIN FT $2800 moo $95,200.00 3,400 $95,20000 0 $000 0 $000 127 2503 521 18" RC PIPE SEWER DESIGN 3006 CLASS III LIN FT $3000 3810 $114,300 00 3,810 $114,30000 0 $000 0 $0 00 128 2503 521 21 "RC PIPE SEWER DESIGN 3006 CLASS III LIN FT $3200 740 $23,68000 740 $23,68D 00 0 $000 0 $000 129 2503 521 24" RC PIPE SEWER DESIGN 3006 CLASS 111 LIN FT $3800 2100 $79,800 00 2,100 $79,80000 0 $000 0 $0.00 130 2503 521 30" RC PIPE SEWER DESIGN 3006 CLASS III LIN FT $4600 280 $12,880.00 280 $12,88000 0 $000 0 $000 131 2503603 CLEAN PIPE SEWER LIN FT $1200 1000 $12,00000 1,000 $12,000DO 0 $000 0 $000 132 25W 602 CONNECTTO EXISTING STORM SEWER EACH $80000 74 $5920000 74 $54,20000 0 $000 0 $0.00 133 25M 501 CONSTRUCT DRAINAGE STRUCTURE DESIGN 48 4020 LIN FT $2]500 280 $]],00000 280 $]]00000 0 $000 0 $000 134 25W 501 CONSTRUCT DRAINAGE STRUCTURE DESIGN 60 4020 LIN FT $40000 90 $36,00000 90 $36,00000 0 $000 0 $0.00 135 25M 501 CONSTRUCT DRAINAGE STRUCTURE DESIGN 72 -4020 LIN FT $55000 40 $22,00000 1 40 $220D0 _Do 0 $000 0 $000 136 25W 501 CONSTRUCT DRAINAGE STRUCTURE DESIGN SPECIAL I EACH $150000 60 $90,00000 60 $9020000 0 $000 0 $0.00 137 2506602 CASTING ASSEMBLY (CATCH BASIN) EACH $75000 111 $83,25000 111 $83,250.00 0 $000 0 $000 138 25W 602 CASTING ASSEMBLY (STORM MANHOLE) EACH $75000 21 $15,]5000 21 $1575000 0 $000 0 $000 139 2105604 G EOTEXTILE FABRIC TYPE IV SO YD $150 200 $30000 200 $30000 0 $000 0 $000 140 2511501 RANDOM RIPRAP CLASS IVTYPE SPECIAL (FIELDSTONE) CU YD $10000 50 $500000 50 $500000 0 $000 0 $000 141 2511 607 RIPRAP GROUT CU YD $20000 20 $400000 20 $4000.00 0 $000 0 $000 142 251160] IN STALL RANDOM RIPRAP CU YD $50.00 50 $2500.00 50 $2,50000 0 $000 0 $000 143 25]3530 STORM DRAIN INLET PROTECTION I EACH I $150.00 182 $2],300.00 182 $27 300 001 0 $0001 0 1 $000 Sch.d.I.D TOt.1- Storm Sewer Improvements $1,108,675.00 $1,108,675.00 $0.00 $O.DD E. Pedestrian Irn rovements - Flagstaff Avenue 144 2104503 REMOVE CONCRETE WALK SOFT $150 24000 $36,00000 24000 $36,00000 0 10.00 $000 145 2105501 COMMONEXCAVATION CU YO $1200 250 $3,000:02 250 $3,00000 0 $0 O0 0 $000 146 2521501 1 4 "CONCRETEWALK I SOFT 1 $4 001 30,000 1 $12000000 1 30,000 1 $120,000.00 1 0 1 $000 $000 147 2575 505 1 SODDING TYPE LAWN(MCL. TOPSOIL B FERT I SO YD 1 $3 501 1,500 1 $5,250.00 1 1,500 1 $5,250.00 1 0 1 $0.00 1 $0.00 Schetlule D TOt.1- Storm Sew. r Improvements $164,250.00 $164,250.00 $0.00 1 $0.00 SUBTOTAL CONSTRUCTION COST $],508,83].00 , 6.5 %CONTINGENCY $4880]441 TOTAL CONSTRUCTION COST $],996,91141 128% INDIRECT $2,239,135.19 11 17,042.0' $391,10]13 $1,429715.00 $92,931.48 $62,08'00 $4,035.20 $0408,14973 $1;]9428192 $1,52264648 $426,34101 $fib, 11520 $1851226 GRAND TOTAL- CONSTRUCTION COST CONTINGENCY +INDIRECT $10,236,046.60 $8,202,431.65 $1,M11,987A9 $84,627.46 APPENDIX C Assessment Map ID — Valley Park and Niakwa Village Assessment Map ID — Cedar Highlands and Dodd Pointe Assessment Roll Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 P 1 C�3fi U�l c o = m R aw m — p as as I� .I � D � \{ - � !`- � - � i � � I % p � / � p Eb ffiJ © ® MG fip CIIi O➢ I x�� j ✓ - -I Is- r � � � �/ � Z 4 / � - �OJ �� © d ~ Q �} � 1 6D @l 6€ RQ ' / /� Ctl ' as .E'`i IL K ' : 2014 Street Reconstruction Project /Io Lakeville, MN Legend Reconst—lion Assessment Rate Parcels _7' Niakwa Village 2nd Assessment Rate Parcels CedarHighlands 5th Assessment Rate Parcels ation ., ' ` ,. t •ti � : - � - � � .., Lakeville 1 121 21 WSB Preliminary Assessment Roll WSB Proiecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fit City ofLakeville Niakma Vifiage2od Addition RAdmtial Pm Uuit AssessmmtRate: 52,166.96 Reviaed: 1012112013 Cedar IBghlaods 5th Addifian Resideofial Per Unit Assessmmt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Fernando WU, Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161sts& -4 161st Shee6162nd Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSBPr j ctNo.: 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT l 031142011016 GEORGE E JANSEN 16255 FOLIAGE AVE ROSEMOUNTMN 55068 -1207 16255 FOLIAGE AVE RESIDENTIAL 1 $4,471.51 $4,471.51 2 031142011016 DAVID J &RACHEL K GARANT 16265 FOLIAGE AVE ROSEMOUNTMN 55068 -1207 16265 FOLIAGE AVE RESIDENTIAL 1 $4,471.51 $4,471.51 3 031142011017 NEHAL &DIPTI PATEL 16037 FLAGSTAFF AVE LAKEVILLE MN 55044 16037 FLAGSTAFF AVE RESIDENTIAL 0.5 $4,471.51 $2,235.76 4 031142011017 TONY YEE 17050 JASPER LN LAKEVILLE MN 55044 16041 FLAGSTAFF AVE RESIDENTIAL 0.5 $4,471.51 $2,235.76 5 031142011017 DARIN ANDERSON POBOX249 CHANHASSEN MN 55317 -0249 16045 FLAGSTAFF AVE RESIDENTIAL 0.5 $4,471.51 $2,235.76 6 031142011017 DARIN ANDERSON POBOX249 CHANHASSEN MN 55317 -0249 16049 FLAGSTAFF AVE RESIDENTIAL 0.5 $4,471.51 $2,235.76 7 1 031142011017 DARIN ANDERSON PO BOX 249 CHANHASSEN MN 55317 -0249 1 16053 FLAGSTAFF AVE RESIDENTIAL 0.5 $4,471.51 $2,235.76 8 031142011017 DARIN ANDERSON POBOX249 CHANHASSEN MN 55317 -0249 16057 FLAGSTAFF AVE RESIDENTIAL 0.5 $4,471.51 $2,235.76 9 031142011017 BALAJI THIAGARAJAN 16061 FLAGSTAFF AVE LAKEVILLE MN 55044 16061 FLAGSTAFF AVE RESIDENTIAL 0.5 $4,471.51 $2,235.76 10 031142011017 DARIN ANDERSON POBOX249 CHANHASSEN MN 55317 -0249 16065 FLAGSTAFF AVE RESIDENTIAL 0.5 $4,471.51 $2,235.76 11 031142011016 DARIN ANDERSON POBOX249 CHANHASSEN MN 55317 -0249 16069 FLAGSTAFF AVE RESIDENTIAL 0.5 $4,471.51 $2,235.76 12 031142011016 ALAN & TOK HUI MACKENTHUN 6228 OXFORD RD S SHAKOPEE MN 55379 16073 FLAGSTAFF AVE RESIDENTIAL 0.5 $4,471.51 $2,235.76 13 031142011016 DEBRA J SCHAEFER 16077 FLAGSTAFF AVE W LAKEVILLE MN 55044 16077 FLAGSTAFF AVE RESIDENTIAL 0.5 $4,471.51 $2,235.76 14 031142011017 DARIN R ANDERSON POBOX249 CHANHASSEN MN 55317 -0249 16081 FLAGSTAFF AVE RESIDENTIAL 0.5 $4471.51 $2,235.76 15 031142011017 REAL VALUE PARTNERS 7725 MARTH CT EDINA MN 55439 16087 FLAGSTAFF AVE RESIDENTIAL 0.5 $4471.51 $2,235.76 16 031142011018 DARIN ANDERSON 7000 YVERDON CT VICTORIA MN 55386 16091 FLAGSTAFF AVE RESIDENTIAL 0.5 $4.471.51 $2,235.76 17 031142011018 DARIN ANDERSON POBOX249 CHANHASSEN MN 55317 -0249 16095 FLAGSTAFF AVE RESIDENTIAL 0.5 $4.471.51 $2,235.76 18 031142011018 MATTHEW J BROMELKAMP 16099 FLAGSTAFF AVE LAKEVILLE MN 55044 16099 FLAGSTAFF AVE RESIDENTIAL 0.5 $4,471.51 $2,235.76 19 031142017008 PAUL L &DIANNE THOMAE 16327 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1863 16327 FLAGSTAFF AVE RESIDENTIAL 1 $4,471.51 $4,471.51 20 031142017008 HEATHER M BARSNESS 16381 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1863 16381 FLAGSTAFF AVE RESIDENTIAL 1 $4,471.51 $4,471.51 21 021142035001 MARK A &JOAN M EHRREICH 16312 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1864 16312 FLAGSTAFF AVE S RESIDENTIAL 1 54,471.51 $4,471.51 22 021142033003 EUGENE SMITH 16064 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1230 16064 FLAGSTAFF AVE W RESIDENTIAL 1 54,471.51 $4,471.51 23 021142033003 CHRISTOPHER C JOHNSON 16082 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1230 16082 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 24 021142033003 JACQUELINE MEIER 16100 FLAGSTAFF AVE ROSEMOUNTMN 55068 -1244 16100 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 25 021142033003 GERALD G &JOYCELYN GRENZ 16190GARNERAVE ROSEMOUNT MN 55068 -1059 16118 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 26. 021142033003 FRANK &KATHY PUCCI 16136 FLAGSTAFF AVE ROSEMOUNTMN 55068 -1244 16136 FLAGSTAFF AVE W RESIDENTIAL 1 34.471.51 $4,471.51 27 021142033003 THOMAS& SANDRA SAUNDERS 16154 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1244 16154 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 28 021142033003 JONATHAN & JESSICA KINNARD 16172 FLAGSTAFF AVE W ROSEMOUNTMN 55068 16172 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 29 021142033002 MAURICE J & T ADAIR SIMMONS 16190 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1270 16190 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 30 021142033002 JERROD J & ASHLEY A WILK 16208 FLAGSTAFF AVE W ROSEMOUNTMN 55068 16208 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 31 021142033002 CARMONL CINCOSKI 16226 FLAGSTAFFAVE W ROSEMOUNT MN 55068 -1280 16226 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 32 031142017007 MICHAEL R& LISA M HENDERSON 16245 FLAGSTAFF AVE ROSEMOUNT MN 550684242 16245 FLAGSTAFF AVE W RESIDENTIAL 1 $4.471.51 $4,471.51 33 031142017008 SCOTTN EBERLE 16301 FLAGSTAFF AVE ROSEMOUNT MN 550684863 16301 FLAGSTAFF AVE W RESIDENTIAL 1 $4.471.51 $4,471.51 34 021142035001 KENNETH R & NOREEN TOLONEN 16306 FLAGSTAFF AVE W ROSEMOUNTMN 550684864 16306 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 35 031142017008 DEBORAH MCRUNNEL 16309 FLAGSTAFF AVE ROSEMOUNT MN 550684863 16309 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 36 031142017008 PATRICIAL JOYCE 16317 FLAGSTAFF AVE ROSEMOUNTMN 55068 16317 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 37 021142035001 JASON HERMAN 16330 FLAGSTAFF AVE ROSEMOUNTMN 55068 -1864 16330 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 38 031142017008 JAMES R &GLORIA J CARVER 16345 FLAGSTAFF AVE ROSEMOUNTMN 55068 -1863 16345 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 39 021142035001 BARRY R & JUDY S HALL 16348 FLAGSTAFF AVE ROSEMOUNTMN 55068 -1864 16348 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 40 031142017008 MARK E & JEANNE M TAYLOR 1750 MORNINGTIDE CT ANCHORAGE AK 99501 16363 FLAGSTAFF AV E W RESIDENTIAL 1 $4,471.51 $4,471.51 41 021142035001 JOHN CHARLES BURGGRAFF 16366 FLAGSTAFF AVE ROSEMOUNT MN 550 68 -1864 16366 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 42 021142035001 BRIAN S & KIM M GULLIVER 16384 FLAGSTAFF AVE W ROSEMOUNT MN 55068 -1864 1 16384 FLAGSTAFF AVE W PARK /OPEN SPACE 1 $4,471.51 $4,471.51 43 031142017008 CHARLES M BECKER PO BOX 309 LAKEVILLE MN 55044 1 16399 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 44 031142017008 VALERIE M SMITH 16401 FLAGSTAFF AVE W ROSEMOUNT MN I 55068m18621 16401 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 Preliminary Assessment Roll WSB P-Jecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Addition RAdmtial Pm Uuit AssessmmtRate: 92,166.96 Reviaed. 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Fernando Wary Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161sts& -4161. Shee6162nd Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSBPr jectNo, 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 45 031142017008 ROBERT D JR & NORA LINN 16415 FLAGSTAFF AVE W ROSEMOUNT MN 55068 16415 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 46 021142035002 RODNEY W & DARLENE HANISH 16416 FLAGSTAFF AVE S ROSEMOUNT MN 55068 16416 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 47 021142035002 MICHAEL J & MARY A DRONEN 16424 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1804 16424 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 48 031142017009 CHARITY PERSSON 16425 FLAGSTAFF AVE S ROSEMOUNT MN 55068 16425 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 49 031142017009 CHEEPCHUCHAI YODSING 16501 FLAGSTAFF AVE LAKEVILLE MN 55068 -1859 16501 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 50 021142035002 JOHNH &DENGLUND 16504 FLAGSTAFF AVE W ROSEMOUNT MN 55068 -1860 16504 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 51 031142017009 PAUL T& ANDREA L SWENSON 16515 FLAGSTAFF AVE ROSEMOUNTMN 55068 -1859 16515 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 52 021142035002 THOMAS D & R NOVOTNY 16516 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1860 16516 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 53 031142017009 DARRELL L SANDSTEDE 16525 FLAGSTAFF ROSEMOUNT MN 55068 16525 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 54 021142035002 SAMUEL KAUFMAN 16526 FLAGSTAFF AVE W ROSEMOUNTMN 55068 16526 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 55 031142071008 JOYCE M& JASON AAYOTTE 16535 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1859 16535 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 56 021142053001 BB.LIE &DMASTERS 16536 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1860 16536 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 57 031142071008 MILO ID & ROYLENE STEPHENS 16545 FLAGSTAFF AV ROSEMOUNT MN 55068 -1859 16545 FLAGSTAFF AVE W RESIDENTIAL 1 $4.471.51 $4,471.51 58 021142053001 MICHAEL L & MARY L SANNAN 16546 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1860 16546 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 59 031142071009 BRADLEY C & JULIE A CARLSON 16555 FLAGSTAFF AVE W ROSEMOUNTMN 55068 16555 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 60 021142053001 SANDEEP &NIDHI GUPTA 15281 DUPONTPATH APPLE VALLEY MN 55124 16556 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 61 031142071009 MARK A BARUM 16565 FLAGSTAFF AVE ROSEMOUNTMN 550684859 16565 FLAGSTAFF AVE W RESIDENTIAL 1 54,471.51 54,471.51 62 021142053001 JONATHAN GLEISNER 1040 COUNTY ROAD 42 E BURNSVILLE MN 55337 16566 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 54,471.51 63 031142071009 STEPHEN MICHAEL KAVITZ 16575 FLAGSTAFF AVE W ROSEMOUNT MN 55068 16575 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 64 021142053001 KEVIN &SUSAN LANDBERG 16576 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1860 16576 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 65 031142071009 MARKA DELUNEY 16601 FLAGSTAFF AVE ROSEMOUNTMN 55068 16601 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 66 021142053001 JYNELL R & JUSTIN M BOULKA 16608 FLAGSTAFF AVE W ROSEMOUNT MN 55068 16608 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 67 031142071009 DONALD A &JUDITH A AUSMUS 16615 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1857 16615 FLAGSTAFF AVE W RESIDENTIAL 1 94,471.51 $4,471.51 68 021142053001 SYLVIA ANNETTE ASHFELD 16616 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1858 16616 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 69 031142071009 DAVID S & CAROL TRUDEAU 16625 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1857 16625 FLAGSTAFF AVE W RESIDENTIAL 1 54,471.51 $4,471.51 70 021142053000 CO HUY & DIANE C VU 16634 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1858 16634 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 71 031142071009 PHILLIPL &LOSS J DENEEN 16635 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1857 16635 FLAGSTAFF AVE W RESIDENTIAL 1 54,471.51 $4,471.51 72 031142071009 TONY W SVIEN 16645 FLAGSTAFF AVE W ROSEMOUNT MN 550684857 16645 FLAGSTAFF AVE W RESIDENTIAL 1 54,471.51 $4,471.51 73 031142071009 SANTIAGO &AMY MATTESON 16655 FLAGSTAFF AVE ROSEMOUNT MN 55068 -1857 16655 FLAGSTAFF AVE W RESIDENTIAL 1 $4.471.51 $4,471.51 74 021142053003 CHRIST OPHERSFLADHAMMER 16656 FLAGSTAFF AVE ROSEMOUNTMN 550684826 16656 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 75 031142071009 LARRY W& LEOPOLDINE SISK 16701 FLAGSTAFF AV ROSEMOUNT MN 550684856 16701 FLAGSTAFF AVE W RESIDENTIAL 1 S4,47L51 $4,471.51 76 021142053003 NATALIE ROSE SAMS 16702 FLAGSTAFF AVE W ROSEMOUNT MN 55068 16702 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 77 031142071010 TIMOTHY RPOPE 16715 FLAGSTAFF ROSEMOUNT MN 550684856 16715 FLAGSTAFF AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 78 021142033001 RICHARD A &RAMONA FOORE 16045 FISHING AVE ROSEMOUNT MN 55068 -1227 16045 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 79 021142033007 MARC A &KARLA RAE BERG 16062 FISHING AVE ROSEMOUNTMN 55068 -1219 16062 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 80 021142033001 THOMAS M &LISA LITKE 16063 FISHING AVE ROSEMOUNT MN 55068 4227 16063FISHNGAVE RESIDENTIAL 1 $4,471.51 $4,471.51 81 021142033001 PAUL J &DEANNA ROBINSON 16081 FISHING AVE ROSEMOUNT MN 55068 -1227 16081 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 82 021142033006 BENEDICT M &JL MCCURDY 16082 FISHING AVE ROSEMOUNT MN 55068 -1219 16082FISHNGAVE RESIDENTIAL 1 $4,471.51 $4,471.51 83 021142033001 MERKAN CORPORATION 706 ROBERT ST S SAINT PAUL MN 55107 -2948 16099 FISHING AVE RESIDENTIAL 1 $4A71.51 $4,471.51 84 021142033006 BARBARA A BOZONIE 16100FISIUNGAVEW ROSEMOUNT MN SS068 -1203 16100 FISHING AVE RESIDENTIAL 1 94,471.51 $4,471.51 85 021142033001 SETH &OBED ORANGI 16117 FISHING AVE ROSEMOUNT MN 55068-120'_ 16117 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 86 021142033006 JULIE SWEETS 7226 E250TH ST ELKOMN 55020 -9472 16118 FISHING AVE RESIDENTIAL 1 144 $4,471.51 87 021142033001 MAIL ED &GEETA GHERAU 16135 FISHING AVE ROSEMOUNT MN 55068 -1201 16135 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 89 021142033006 JOHN W & LISA D GARBERT 16136 FISHING AVE ROSEMOUNT MN 55068 -1203 16136 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 Preliminary Assessment Roll WSB P-Jec& 2014 S &eetReconstrucaon Project R —txoct Proposed Re idmdal Pet Uuit Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Adding, Restdmttal Pm Uuit Ass ®smmtRate: 92,166.96 Reviaed. 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Fai,Ween Avenue, Fantasia Avenge, Farcry Way, Fernand, Avenue, Fernando WU, Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FkgslaffWav, Fo"ge Avenge, Lower 161sts&ee4 161. S&-4 162.d S&ee6163rd Street, 164& S&eet, Lower 169th Stree 4 169th S &eef, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 Gearge[awn Way, I70th S&e4 I70th Court WSBPr jectNo, 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 89 021142033002 DAVID L & ROXANN BERGQUIST 16153 FISHING AVE ROSEMOUNT MN 55068 -1202 16153 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 90 021142033006 ROBERT J STOMMES 16172 FISHING AVE ROSEMOUNT MN 55068 -1203 16172 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 91 021142033006 LYUDMILA& GALINA GUTSALYUK 16190 FISHING AVE ROSEMOUNT MN 55068 -1203 16190FISHNGAVE RESIDENTIAL 1 $4,471.51 $4,471.51 92 021142033002 RUBIN E ZINGLER 16207 FISHING AVE ROSEMOUNT MN 55068 -1225 16207 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 93 021142033006 CHHAY UN 16208 FISHING AVE ROSEMOUNT MN 55068 -1226 16208 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 94 021142033006 GREGORY& BECKY MALISZEWSKI 16242 FISHINGAVE ROSEMOUNT MN 55068 -1226 16242 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 95 021142035006 LINDA RODRIGUEZ NUNEZ 16312 FISHING AVE .W ROSEMOUNT MN 55068 -1407 16312 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 96. 021142035000 MARTHA ADAMS 16317 FISHING AVE ROSEMOUNT MN 55068 -1419 16317 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 97 021142035006 JOSEPH W& JUDITH HELGESTAD 16320 FISHING AVE ROSEMOUNT MN 55068 -1407 16320 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 98 021142035000 TERRY M RAYMOND 16323 FISHING AVE ROSEMOUNT MN 55068 -1419 16323 FISHING AVE RESIDENTIAL 1 S4,471.51 $4,471.51 99 021142035000 ILENE RILEY 16335 FISHING AVE ROSEMOUNT MN 55068 -1419 16335 FISHING AVE RESIDENTIAL 1 54,471.51 $4,471.51 100 021142035006 JEROME L & KATHLEEN AWE 16338 FISHING AVE ROSEMOUNT MN 55068 -1407 16338FISHINGAVE RESIDENTIAL 1 $4,471.51 $4,471.51 101 021142035000 BARRY R &JUDY S HALL 16348 FLAGSTAFF AVE ROSEMOUNT MN 55068 16347 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 102 021142035000 JOE BRUNETTE 16365 FISHING AVE ROSEMOUNT MN 55068 -1400 16365 FISHING AVE RESIDENTIAL 1 S4A7L51 $4,471.51 103 021142035008 FISHING AVENUE LLC 4705138TH STW APPLEVALLEYMN 55124 16376 FISHING AVE RESIDENTIAL 1 SL47L51 $4,471.51 104 021142035008 CURTIS &DIANE GNERER 16394FISHINGAVE ROSEMOUNT MN 550684436 16394 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 105 021142035004 JAMES SR &VIDA R PETERSON 16450 FISHING AVE ROSEMOUNT MN 55068 16450FISHINGAVE RESIDENTIAL 1 $4,471.51 $4,471.51 106 021142035001 GB.BERTE &GINA L ENGEL 16455 FISHING AVE ROSEMOUNT MN 550684435 16455 FISHING AVE RESIDENTIAL 1 $4,471.51 SL47L51 107 021142035004 NGAN HUU NGUYEN 16468 FISHING AVE ROSEMOUNT MN 55068 16468 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 108 021142035005 BRIAN R &KATHRYN GROLLA 16486 FISHING AVE ROSEMOUNT MN 55068 -1418 16486 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 109 021142035002 BRIAN M &AMY S KILMARTIN 16491 FISHING AVE ROSEMOUNT MN 550684435 16491 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 110 021142035005 MARILYN E FREIDLUND 16504 FISHING AVE ROSEMOUNT MN 55068 -1433 16504 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 111 021142035002 GARY LOWE 16509FISHINGAVE ROSEMOUNT MN 550684434 16509 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 112 021142035005 MARK ANDERSON 16522 FISHING AVE ROSEMOUNT MN 55068 -1433 16522 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 113 021142053000 DANIEL W &MTHOMPSON 16527 FISHING AVE ROSEMOUNT MN 55068 -1434 16527 FISHING AVE RESIDENTIAL 1 $4,471.51 54,471.51 114 021142053000 WILLIAM F & TRESA K GARR 16545 FISHING AVE ROSEMOUNT MN 55068 -1434 16545 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 115 021142053000 LISAMMCCARTHY 16563 FISHING AVE ROSEMOUNT MN 55068 -1434 16563 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 116 021142053004 JAC UELINE MARY DZRJK 16580 FISHING AVE ROSEMOUNT MN 550684433 16580 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 117 021142053000 EDWARDA &VLORENZEN 16581 FISHING AVE ROSEMOUNTMN 55068-1434 16581 FISHING AVE RESIDENTIAL 1 $4,471.51 $4,471.51 118 021142033006 RICKY FRAZIER 16154 FISHING AVE S ROSEMOUNT MN 55068 16154 FISHING AVE S RESIDENTIAL 1 $4,471.51 $4,471.51 119 021142033002 ARLYN DUANE NELSON 16171 FISHING AVE S ROSEMOUNT MN 55068 16171 FISHING AVE S RESIDENTIAL 1 $4,47L51 $4,471.51 120 021142033002 RHONDA KAY SCHILLINGER 16189 FISHING AVE S ROSEMOUNT MN 55068 16189 FISHING AVE S RESIDENTIAL 1 $4,471.51 $4,471.51 121 021142035002 JAMES W & LORELEI M HOVER 16473 FISHING AVE S ROSEMOUNTMN 55068 16473 FISHING AVE S RESIDENTIAL 1 $4,471.51 $4,471.51 122 021142053000 CHRISTOPHER W REAGAN 16599 FISHING AVE S ROSEMOUNT MN 55068 16599 FISHING AVE S RESIDENTIAL 1 $4,471.51 $4,471.51 123 021142033002 STEVEN A & GERALYN ONEILL 16225 FISHING AVE W ROSEMOUNTMN 55068 -1225 16225 FISHING AVE W RESIDENTIAL 1 $4,471.51 $4,471.51 124 021142033002 EUGENE & TIMOTHY BREITER 6435 163RD ST W ROSEMOUNT MN 55068 -1416 6435 163RD ST W RESIDENTIAL 1 $4,471.51 $4,471.51 125 021142035000 ANNE B BOGER 6440 163RD ST W ROSEMOUNT MN 55068 6440 163RD STW RESIDENTIAL 1 $4,471.51 $4,471.51 126 021142035001 ARNOLD J & S K MOLDE 6450 163RD ST W ROSEMOUNT MN 55068 -1401 6450 163RD ST W RESIDENTIAL 1 $4,471.51 $4,471.51 127 021142033002 RICHARD M & S KADRLBC 6455 163RD ST W ROSEMOUNT MN 55068 - 1416 6455 163RD ST W RESIDENTIAL 1 94,471.51 $4,471.51 128 021142035000 EDWIN & LEANN WHITE 6435 164TH ST W ROSEMOUNT MN 550684424 6435 164TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 129 021142035001 LISA M NOLAN 6440 164TH ST W ROSEMOUNTMN 55068 -1402 6440 164TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 130 021142035000 GARY & JACQUELINE DBLCKS 6455 164TH STW ROSEMOUNT MN 550684424 6455 164TH STW I RESIDENTIAL 1 $4,471.51 $4,471.51 131 021142035001 MARY JO MAINOR 6460 164TH ST W ROSEMOUNTMN 55068 -1402 6460 164TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 132 021142035000 MICHAEL & T SCHIMSCHOCK 6475 164TH ST W ROSEMOUNTMN 55068 -1424 6475 164TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 Preliminary Assessment Roll WSB P-Jecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Addition Restdmtial Pm Uuit AssessmmtRate: 92,166.96 Reviaed: 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr4 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Femando WU, Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161sts& -4 161. S&-4 162.d Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSBPr jctNo.: 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 133 021142035002 DIANE M DEGOLIER 6480 164TH ST W ROSEMOUNT MN 55068 -1402 6480 164TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 134 021142037000 ILENE C BENESH 16410 FLAGSTAFF WAY ROSEMOUNT MN 55068 -1409 16410 FLAGSTAFF WAY RESIDENTIAL 1 $4,471.51 $4,471.51 135 021142053004 DAVID A LEARD 16593 FLAGSTAFF WAY ROSEMOUNT MN 55068 -1462 16593 FLAGSTAFF WAY RESIDENTIAL 1 $4,471.51 $4,471.51 136 021142037000 HEATHER THOMAS W STUTZ 16420 FLAGSTAFF WAY ROSEMOUNT MN 55068 -1409 16420 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 137 021142037001 KEVIN L PERRY 16430 FLAGSTAFF WAY W ROSEMOUNT MN 55068 -1409 16430 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 138 021142037001 ANDREW J SB.BERNAGEL 16440 FLAGSTAFF WAY W ROSEMOUNT MN 55068 16440 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 139 021142037002 ROBERT RRINKENBERGER 16443 FLAGSTAFF WAY W ROSEMOUNT MN 55068 -1464 16443 FLAGSTAFF WAY W RESIDENTIAL 1 $4.471.51 $4,471.51 140 021142037001 NATHANAEL BERNAL 16450 FLAGSTAFF WAY W ROSEMOUNT MN 55068 16450 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 141 021142037001 JEROME L BRAUN 16460 FLAGSTAFF WAY ROSEMOUNT MN 55068 -1409 16460 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 142 021142037001 WILLIAM JJOHNSON 16470 FLAGSTAFF WAY ROSEMOUNT MN 55068 -1409 16470 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 143 021142037002 ANDREW P ANDERSON 16473 FLAGSTAFF WAY W ROSEMOUNT MN 55068 -1464 16473 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 144 021142037001 JOHN D &HELEN JCHDWOOD 16480 FLAGSTAFF WAY ROSEMOUNT MN 55068 -1409 16480 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 145 021142037002 TAMARA LYNN FOX 16483 FLAGSTAFF WAY ROSEMOUNT MN 55068 -1464 16483 FLAGSTAFF WAY W RESIDENTIAL 1 $4.471.51 $4,471.51 146 021142037001 MARGARET J GB.LARD 16490 FLAGSTAFF WAY ROSEMOUNT MN 55068 -1409 16490 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 147 021142035004 WENTON &BARBARA WAGNER 16493 FLAGSTAFF WAY ROSEMOUNT MN 550684464 16493 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 148 021142037001 GLENN E & HAZEL ONBERG 16500 FLAGSTAFF WAY ROSEMOUNT MN 55068 -1452 16500 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 149 1 021142035004 JASON C &ELIZABETH MOEN 16503 FLAGSTAFF WAY W LAKEVILLE MN 55068 -1453 16503 FLAGSTAFF WAY W RESIDENTIAL 1 54,471.51 $4,471.51 150 021142053003 JOHN D & DANIELA D COLLINS 16510 FLAGSTAFF WAY ROSEMOUNT MN 55068 16510 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 54,471.51 151 021142035003 RALPH JR & JONI FORREST 16513 FLAGSTAFF WAY ROSEMOUNT MN 550684453 16513 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 152 021142053003 MARY J COOK 16520 FLAGSTAFF WAY ROSEMOUNT MN 55068 -1452 16520 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 153 021142035003 LARRY & DEBRA ADAMS 16523 FLAGSTAFF WAY ROSEMOUNT MN 550684453 16523 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 154 021142053001 WILLIAM W TOMASULO 16530 FLAGSTAFF WAY ROSEMOUNT MN 55068 -1452 16530 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 155 021142035003 RANDALL J & BARBARA PETERSON 16533 FLAGSTAFF WAY ROSEMOUNT MN 550684453 16533 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 156 021142053001 STEVEN J & GAIL M COTE 16540 FLAGSTAFF WAY ROSEMOUNT MN 550684452 16540 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 157 021142053004 JAMES B & JOAN DUERKSEN 16543 FLAGSTAFF WAY ROSEMOUNT MN 550684453 16543 FLAGSTAFF WAY W RESIDENTIAL 1 S4,47L51 $4,471.51 158 021142053001 DOUGLAS & JMULVB.LE 16550 FLAGSTAFF WAY ROSEMOUNT MN 550684463 16550 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 159 021142053004 MICHAEL J & JUDITH A WALD 16553 FLAGSTAFF WAY ROSEMOUNTMN 55068 -1462 16553 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 160 021142053002 MICHAEL J & VICKY PERSING 16560 FLAGSTAFF WAY ROSEMOUNT MN 550684463 16560 FLAGSTAFF WAY W RESIDENTIAL 1 54,471.51 $4,471.51 161 021142053004 THOMAS R & KELLY ILIMBACK 16563 FLAGSTAFF WAY ROSEMOUNTMN 55068 -1462 16563 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 162 021142053002 MARY ANN CROLLEY 3500 40TH AVES MINNEAPOLIS MN 55406 16570 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 163 021142053004 SEAN P &JULIE A SMITH 16573 FLAGSTAFF WAY ROSEMOUNTMN 55068 -1462 16573 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 164 021142053002 DAN& MELISSA POLENCHECK 16580 FLAGSTAFF WAY W ROSEMOUNT MN 55068 16580 FLAGSTAFF WAY W RESIDENTIAL I $4,471.51 $4,471.51 165 021142053004 NORMA J KLEMM 16583. FLAGSTAFF WAY ROSEMOUNT MN 550684462 16583 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 166 021142053002 CAROL A HARKNESS 16590 FLAGSTAFF WAY ROSEMOUNT MN 550684463 16590 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 167 021142053002 JOHN W & SUSAN EUBANKS 16600 FLAGSTAFF WAY ROSEMOUNT MN 550684461 16600 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 168 021142053004 MICHAEL & DIANE NEWMAN 16603 FLAGSTAFF WAY ROSEMOUNTMN 55068 -1459 16603 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 169 021142053002 SAMUEL ESHETE 16610 FLAGSTAFF WAY W ROSEMOUNTMN 55068 16610 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 170 021142053004 1 CURTIS & KIMBERLY GUNDERSON 16617 FLAGSTAFF WAY ROSEMOUNT MN 550684459 16617 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 171 021142053002 TERRENCEP &DAWNMCARR 16620 FLAGSTAFF WAY ROSEMOUNT MN 550684461 16620 FLAGSTAFF WAY W RESIDENTIAL 1 $4.471.51 $4,471.51 172 021142053002 DAKOTA C OUNTY CDA 1228 TOWN CENTRE DR EAGAN MN 55123 16630 FLAGSTAFF WAY W RESIDENTIAL 1 94,471.51 $4,471.51 173 021142053000 RONALD & LUPE KALSTABAKKEN 16639 FLAGSTAFF WAY ROSEMOUNT MN 550684460 16639 FLAGSTAFF WAY W RESIDENTIAL 1 54,471.51 $4,471.51 174 021142053002 CHERYL ANN & BRUCE C JOHNSON 16640 FLAGSTAFF WAY ROSEMOUNT MN 550684461 16640 FLAGSTAFF WAY W RESIDENTIAL 1 54,471.51 $4,471.51 175 021142053003 KELLY C & PATRICIA ROBERTSON 16650 FLAGSTAFF WAY ROSEMOUNTMN 55068 -1461 16650 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 176 021142053000 JOEL L & DEBORAH J NICKERSON 16653 FLAGSTAFF WAY ROSEMOUNT MN 550684460 16653 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 I $4,471.51 Preliminary Assessment Roll WSB P-Jecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Addition Restdmtial Pm Uuit AssessmmtRate: 92,166.96 Reviaed. 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Fernando WU, Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161sts& -4161. S&-4 162.d Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSBPr jectNo, 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 177 021142053003 TIMOTHY M & SANDRA L MURPHY 16660 FLAGSTAFF WAY ROSEMOUNT MN 55068 -1461 16660 FLAGSTAFF WAY W RESIDENTIAL 1 $4,471.51 $4,471.51 178 021142031000 SCOTT &MICHOL J STONE. 6039 LOWER 161ST ST ROSEMOUNT MN 55068 -1316 6039 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 179 021142031007 TIMOTHY D &STACYL IVERSON 6044 LOWER 161ST ST W ROSEMOUNT MN 55068 -1313 6044 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 180 021142031000 KEITHL& JUNDEE ANDERSON 6075 LOWER 161ST ST ROSEMOUNT MN 55068 -1316 6075 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 181 021142031000 JUNE ANDERSON 6093 LOWER 161ST ST ROSEMOUNT MN 55068 -1316 6093 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 182 021142031000 KENT D& LISA M HALVORSON 6129 LOWER 161ST ST ROSEMOUNT MN 55068 -1315 6129 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 183 021142031007 DAVID C &NIKKI AKEHURST 6170 LOWER 161ST ST ROSEMOUNTMN 55068 -1318 6170 LOWER 161ST ST RESIDENTIAL 1 $4.471.51 $4,471.51 184 021142031001 DAVID M &LORETTAIT SWARTZ 6201 LOWER 161ST ST ROSEMOUNTMN 55068 -1214 6201 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 185 021142031007 ANTHONY D PAYETTE 6206 LOWER 161ST ST ROSEMOUNT MN 55068 -1204 6206 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 186 021142031001 DONNIE M & SHEROND FREEMAN 6219 LOWER 161ST ST ROSEMOUNTMN 55068 -1214 6219 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 187 021142033000 PHILLIP A SPURGIN 6263 LOWER 161STW ROSEMOUNT MN 55068 6263 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 188 021142033003 PETR& NADEZHDA AFANASYEV 6268 LOWER 161ST ST ROSEMOUNT MN 55068 -1224 6268 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 189 021142033000 STEVEN C& KIMBERLY LORENZ 6281 LOWER 161STW ROSEMOUNTMN 55068 -1213 6281 LOWER 161ST ST RESIDENTIAL 1 $4.471.51 $4,471.51 190 021142033003 MITCHELL J& COLLEEN GILOMEN 6286 LOWER 161ST ST ROSEMOUNT MN 55068 -1224 6286 LOWER 161ST ST RESIDENTIAL 1 $4.471.51 $4,471.51 191 021142033000 NATHAN J & MIRIAM S BAWDEN 6317 LOWER 161ST ST ROSEMOUNT MN 55068 -1210 6317 LOWER 161 ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 192 021142033004 JOHN & MARY KAY STEELE 6322 LOWER 161ST ST ROSEMOUNTMN 55068 -1211 6322 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 193 021142033004 MYRONJ& DEBORAH DRELLACK 6340 LOWER 161ST ST W ROSEMOUNT MN 55068 -1211 6340 LOWER 161ST ST RESIDENTIAL 1 54,471.51 $4,471.51 194 021142033000 ELIZABETH SCHRUPP 6353 LOWER 161ST ST ROSEMOUNT MN 55068 6353 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 195 021142033001 MICHAEL B & SUSAN J STAHNKE 6407 LOWER. 161ST ST ROSEMOUNTMN 55068 -1209 6407 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 196 021142033001 JAMES E &JONIM WEAVER 6425 LOWER. 161ST ST ROSEMOUNT MN 55068 -1209 6425 LOWER 161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 197 021142031000 ERIK D SIEBRECHT 6021 LOWER 161ST ST W ROSEMOUNTMN 55068 -1316 6021 LOWER 161ST STW RESIDENTIAL 1 $4,471.51 $4,471.51 198 021142031006 DENNIS M & LAURA IKLEVEN 6026 LOWER 161ST ST ROSEMOUNT MN 55068 -1313 6026 LOWER 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 199 021142031000 GARY S& PAULETTE HAYDEN 6057 LOWER 161ST ST ROSEMOUNTMN 55068 -1316 6057 LOWER 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 200 021142031007 DANIEL P ELLENSON 6062 LOWER 161ST ST W ROSEMOUNTMN 55068 6062 LOWER 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 201 021142031007 6080161ST ST LLC 10583202ND STW LAKEVILLE MN 55044 6080 LOWER 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 202 021142031007 SHAKIL AMARUF 6098 LOWER 161ST ST W ROSEMOUNT MN 55068 6098 LOWER 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 203 021142031000 RANDY R & MICHELLE IKRAFT 6111LOWER161ST STW ROSEMOUNT MN 55068-13541 6111 LOWER 161ST ST W RESIDENTIAL 1 54,471.51 $4,471.51 204 021142031007 MARKS &KELLYJLEGG 6116 LOWER 161ST ST W ROSEMOUNTMN 55068 -1352 6116 LOWER 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 205 021142031007 GREGORY J STEINKOPE 6134 LOWER 161ST ST W ROSEMOUNT MN 55068 -1318 6134 LOWER 161ST ST W RESIDENTIAL 1 $4.471.51 $4,471.51 206 021142031000 MARK I & TRACY L HAGLUND 6147 LOWER 161ST ST W ROSEMOUNT MN 55068 -1315 6147 LOWER 161ST ST W RESIDENTIAL 1 $4.471.51 $4,471.51 207 021142031007 PATRICK S & JESSICA JOYCE 6152 LOWER 161ST ST W ROSEMOUNT MN 55068 -1318 6152 LOWER 161ST ST W RESIDENTIAL I $4,471.51 $4,471.51 208 021142031000 JAMES & HEATHER BROWN 6165 LOWER 161ST ST W ROSEMOUNT MN 55068 -1355 6165 LOWER 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 209 021142031001 KELLI KNESS 6183 LOWER 161ST ST W ROSEMOUNT MN 55068 -1355 6183 LOWER 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 210 021142031007 BRETT E MELTON 6188 LOWER 161ST ST W ROSEMOUNTMN 55068 -1318 6188 LOWER 161ST STW RESIDENTIAL 1 $4,471.51 $4,471.51 211 021142031008 ISLAND MARINE PROPERTIES LLC 13558 GLASGOW IN APPLEVALLEYMN 55124 6224 LOWER 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 212 021142033000 JEANNEMPOTTH 6245 LOWER 161ST ST W ROSEMOUNT MN 55068 -1213 6245 L OWER 161 ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 213 021142033003 STEVEN GISCH 6250 16 1 ST STW I LAKEVB.LEMN 55044 6250 LOWER161STSTW RESIDENTIAL 1 $4,471.51 $4,471.51 214 021142033000 GORDON B & LOUISE L LUNDQUIST 6299 LOWER 161ST ST W ROSEMOUNT MN 55068 -1213 6299 LOWER 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 215 021142033000 CHRISTOPHER & CHERYL BJERKE 6335 LOWER 161ST ST W ROSEMOUNT MN 55068 -1210 6335 LOWER 161ST STW RESIDENTIAL 1 $4.471.51 $4,471.51 216 021142033004 STEVENJBLANDA 6352 LOWER 161ST STW ROSEMOUNT MN 55068-12111 6352LOWER161ST STW RESIDENTIAL 1 $4,471.51 $4,471.51 217 021142033001 LARRY M KENDRICK 6371 LOWER 161STST W ROSEMOUNT MN 55068 -1210 1 6371 LOWER 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 218 021142033001 BEAL BANK SSB 1 CORPORATE DR STE 360 LAKE ZURICH B. 60047 -8945 1 6389 LOWER 161ST ST W RESIDENTIAL 1 1 1 $4,471.51 $4,471.51 219 021142033005 LINDA SMITH 16063 FINLAND AVE ROSEMOUNT MN 55068 -1232 1 16063 FINLAND AVE RESIDENTIAL 1 54,471.51 $4,471.51 220 021142033005 CHRISTOPHER &LINDA ANTON 16081 FINLAND AVE ROSEMOUNT MN 55068 -1232 1 16081 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 Preliminary Assessment Roll WSB P-Jecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Addition RAdmtial Pm Uuit AssessmmtRate: 52,166.96 Reviaed: 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Femando Wary Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161sts& -4161. S&-4 162.d Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSBPr jctNo.: 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 221 021142033004 JOSHUA &MARIAN OLSON 16082 FINLAND AVE ROSEMOUNT MN 55068 -1218 16082 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 222 021142033005 TIMOTHY E & LORI L GENIA 16099 FINLAND AVE ROSEMOUNT MN 55068 -1232 16099 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 223 021142033004 JOLYNB ERICKSEN 16100 FINLAND AVE ROSEMOUNT MN 55068 -1231 16100FINLANDAVE RESIDENTIAL 1 $4,471.51 $4,471.51 224 021142033004 JOSEPH E &MARY GUIDOTH 16118 FINLAND AVE ROSEMOUNTMN 55068 -1231 16118 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 225 021142033005 JAMIE WREN 16135 FINLAND AVE ROSEMOUNTMN 55068 -1228 16135 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 226 021142033005 TIMOTHY P &KIM LITTLE 16153 FINLAND AVE ROSEMOUNTMN 55068 -1228 16153 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 227 021142033007 LORI E REIS 16156. FINLAND AVE ROSEMOUNT MN 55068 16156 FINLAND AVE RESIDENTIAL 1 S4.471.51 $4,471.51 228 021142033005 JAMESRMYRAH 16171 FINLAND AVE. ROSEMOUNT MN 55068 16171 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 229 021142033005 STEVEN &MARILYN BROWN 16207 FINLAND AVE ROSEMOUNT MN 55068 -1438 16207 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 230 021142033008 CHESTER C &PA GATCHELL 16212 FINLAND AVE ROSEMOUNT MN 55068 -1439 16212 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 231 021142033006 PATRICK I & MARLENE WALSH 16225 FINLAND AVE ROSEMOUNTMN 55068 -1438 16225 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 232 021142033008 MICHAEL T NIEDZIELSKI 16230FINLANDAVE ROSEMOUNT MN 55068 -1439 16230 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 233 021142033008 SUSAN DEHIN 16248 FINLAND AVE ROSEMOUNTMN 55068 -1439 16248 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 234 021142035006 KELLY &MARY ANN MCCANN 16266 FINLAND AVE ROSEMOUNTMN 55068 -1439 16266 FINLAND AVE RESIDENTIAL 1 $4,471.51 $4,471.51 235 021142033005 GREGORY J BUDWEG 16117 FINDLAND AVE 8 ROSEMOUNTMN 55068 16117 FINLAND AVE S RESIDENTIAL 1 $4,471.51 $4,471.51 236 021142033005 EUGENE H & DENICE A RAHN 16189 FINLAND AVE S ROSEMOUNT MN 55068 16189 FINLAND AVE S RESIDENTIAL 1 $4,471.51 $4,471.51 237 021142033009 JEFFREY P & LESLIE SNELSON 16204 FISHING WAY ROSEMOUNT MN 55068 -1408 16204 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 238 021142033009 MATTHEW QUIST 269447TH ST IER GROVE HEIGHTS 55076 16216. FISHING WAY RESIDENTIAL 1 54,471.51 $4,471.51 239 021142033009 CHRISTOPHER & PAIGE WALSH 16228 FISHING WAY ROSEMOUNT MN 55068 -1408 16228 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 240 021142033009 BRENDEN E & SOPHIA AMURPHY 16229 FISHING WAY ROSEMOUNT MN 55068 -1432 16229 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 241 021142033009 CAMILLE A PETRI 16240 FISHING WAY ROSEMOUNT MN 55068 -1408 16240 FISHING WAY RESIDENTIAL 1 54,471.51 $4,471.51 242 021142033008 CAMILLA J HAMILTON 16251 FISHING WAY ROSEMOUNTMN 55068 -1432 16251 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 243 021142035007 JAMES J & NANCY KILL 16252 FISHING WAY ROSEMOUNT MN 55068 -1408 16252 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 244 021142035007 JAMES M & SARAH K SNODGRASS 16263 FISHING WAY ROSEMOUNT MN 55068 -1432 16263 FISHING WAY RESIDENTIAL 1 S4 ,471.51 $4,471.51 245 021142035007 CYNTHIA M& DAVID R TARALDSON 16264 FISHING WAY ROSEMOUNT MN 55068 -1408 16264 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 246 021142035007 HOLLY MARIE MEYER 16275 FISHING WAY ROSEMOUNTMN 55068 -1432 16275 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 247 021142035007 SILV IA G BOUNCE 16276 FISHING WAY ROSEMOUNT MN 55068 16276 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 248 021142035007 THOMAS G & SHARON ROURKE 16287 FISHING WAY ROSEMOUNT MN 55068 -1432 16287 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 249 021142035007 JUSTINE M MILLS 16288 FISHING WAY ROSEMOUNT MN 55068 -1408 16288 FISHING WAY RESIDENTIAL 1 $4.471.51 $4,471.51 250 021142035007 CORNELL M &NICOLE A LOFTON 16300 FISHING WAY ROSEMOUNTMN 55068 -1431 16300 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 251 021142035007 VINCENT CAPRA 16305FISIUNGWAY ROSEMOUNT MN 55068 16305 FISHING WAY RESIDENTIAL I $4,471.51 $4,471.51 252 021142035007 BRUCE& JO PETERSON 16312 FISHING WAY ROSEMOUNT MN 55068 -1431 16312 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 253 021142035006 MEGAN HAMMERLINDL 16321 FISHING WAY ROSEMOUNT MN 55068 16321 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 254 021142035008 STEPHEN & DEBRA WELTERS 16324 FISHING WAY ROSEMOUNT MN 55068 -1431 16324 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 255 021142035008 COREY CHRISTENSEN 16358 FISHING AVE ROSEMOUNT MN 55068 -1436 16358 FISHING WAY RESIDENTIAL 1 $4,471.51 $4,471.51 256 021142033010 THOMAS K & LYNN E HINRICHS 16211 FINCH WAY ROSEMOUNT MN 55068 -1447 16211 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 257 021142033009 PAMELA J MUELLER 16221 FINCH WAY ROSEMOUNT MN 55068 -1447 16221 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 258 021142033009 CHARLES F & CINDY COFFIN 16235 FINCH WAY ROSEMOUNT MN 55068 -1447 1 16235 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 259 021142033009 DAVIDB TSTE GUSTAFSON 16249 FINCH WAY ROSEMOUNT MN 55068 -1447 1 16249FINCHWAY RESIDENTIAL 1 S4 ,471.51 $4,471.51 260 021142035009 MARC K & BARBARA J BJERKE 16263 FINCH WAY ROSEMOUNT MN 55068 -1447 16263 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 261 021142037000 THEODORE R & SUSAN A TF.LLMAN 16276 FINCH WAY ROSEMOUNT MN 55068 -1405 16276 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 262 021142035009 FEW ARDC &JANE M JACOBUS 16277FINCHWAY ROSEMOUNT MN 1 55068 -1447 1 16277 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 263 021142035009 HEATHER L FUNARI 16291 FINCH WAY ROSEMOUNT MN 55068-1447 16291 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 264 021142035009 GRANT J & DIANE C POPEHN 16298 FINCH WAY ROSEMOUNT MN 55068 -1405 16298 FINCH WAY RESIDENTIAL 1 54,471.51 $4,471.51 Preliminary Assessment Roll WSB P-Jecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Addition RAdmtial Pm Uuit AssessmmtRate: 92,166.96 Reviaed: 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Femando ThU, Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161sts& -4161. S&-4 162.d Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSBPr jctNo.: 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 265 021142035009 REBECCA S MADDAS 16305 FINCH WAY ROSEMOUNT MN 55068 -1446 16305 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 266 021142035008 SAYBAH KORLU CEPHAS 16319 FINCH WAY W ROSEMOUNTMN 55068 -1446 16319 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 267 021142035009 JAMES P & MELISSA A CHRISTIANSEN 16326 FINCH WAY ROSEMOUNT MN 55068 -1445 16326 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 268 021142035008 OKECHUKWU NNAJI 16333 FINCH WAY W ROSEMOUNT MN 55068 -1446 16333 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 269 021142035009 RONALD E& ANNEMARIE WAGES 16340 FINCH WAY ROSEMOUNTMN 55068 -1445 16340 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 270 021142035008 STEPHEN D VOEGELI 16347 FINCH WAY ROSEMOUNT MN 55068 -1446 16347 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 271 021142035009 TERESA L WEASLER 16354 FINCH WAY ROSEMOUNT MN 55068 -1445 16354 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 272 021142035008 SCOT C. WOOLF 16361 FINCH WAY ROSEMOUNT MN 55068 -1446 16361 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 273 021142035009 MICHAEL BRYON SPACKMAN 2835 TANGLEROSE PL N EAGLET[) 83616 16368 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 274 021142035008 WILLIAM &GAIL EMERSON 16375FINCHWAY ROSEMOUNT MN 55068 -1446 16375 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 275 021142035004 ALLEN F &DIANA M KUGLER 16382 FINCH WAY ROSEMOUNT MN 55068 -1429 16382 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 276 021142035004 MATTHEW A JACOBSON 16388 FINCH WAY ROSEMOUNT MN 55068 16388 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 277 021142035008 WARREN L &BETTY A JACKSON 16389 FINCH WAY ROSEMOUNT MN 55068 -1446 16389 FINCH WAY RESIDENTIAL 1 $4.471.51 $4,471.51 278 021142035004 DAVIDRLEEDER 16396FINCHWAYW ROSEMOUNT MN 55068 16396FINCHWAY RESIDENTIAL 1 $4.471.51 $4,471.51 279 021142035004 JOHN R &KAREN L COMPTON 16402 FINCH WAY ROSEMOUNT MN 550684444 16402 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 280 021142035004 JOHN & CHERYL LINDENBERG 16410 FINCH WAY ROSEMOUNT MN 550684444 16410 FINCH WAY RESIDENTIAL 1 $4,471.51 $4,471.51 281 021142035004 JANETHAWES 16432FINCHWAYW LAKEVILLE MN 55068 16432 FINCH WAY RESIDENTIAL 1 54,471.51 $4,471.51 282 021142035009 GALEN M FRANZ 16312 FINCH WAY S ROSEMOUNT MN 55068 16312 FINCH WAY S RESIDENTIAL 1 $4,471.51 $4,471.51 283 021142031001 DOUGLAS & PATRICIA DUCHENE 16200 FERNANDO WAY ROSEMOUNT MN 550684404 16200 FERNANDO AVE RESIDENTIAL 1 $4,471.51 $4,471.51 284 021142031009 DAVIDD &REBECCA GOETZ 16209 FERNANDO WAY ROSEMOUNT MN 55068 16209 FERNANDO AVE RESIDENTIAL 1 $4,471.51 $4,471.51 285 021142031001 MATTHEW T &MEGAN RDIMICH 16236 FERNANDO WAY ROSEMOUNT MN 55068 16236 FERNANDO AVE RESIDENTIAL 1 $4,471.51 $4,471.51 286 021142031009 DEBRA ANN KNUTSON 16245 FERNANDO WAY ROSEMOUNT MN 55068 16245 FERNANDO AVE RESIDENTIAL 1 $4,471.51 $4,471.51 287 021142031001 JEFFERY& CINDY NEUDECKER 16254 FERNANDO WAY ROSEMOUNTMN 550684404 16254 FERNANDO AVE RESIDENTIAL 1 $4,471.51 $4,471.51 288 021142037002 JEDEE R & ALESHA K CHUA 16317 FERNANDO WAY ROSEMOUNT MN 55068 16317 FERNANDO AVE RESIDENTIAL 1 $4,471.51 $4,471.51 289 021142037002 RONALD &PAULA KELLY 16347 FERNANDO WAY ROSEMOUNT MN 55068 -1403 16347 FERNANDO AVE RESIDENTIAL 1 54,471.51 $4,471.51 290 021142031001 JIM E PERRY 16218 FERNANDO WAY ROSEMOUNT MN 55068 16218 FERNANDO AVE S RESIDENTIAL 1 54,471.51 $4,471.51 291 021142031009 MARK W & DAWN A TOTH 16227 FERNANDO WAY ROSEMOUNT MN 550684413 16227 FERNANDO WAY RESIDENTIAL 1 54,471.51 $4,471.51 292 021142031009 WILLIAM E &ALICE BRUN 16263 FERNANDO WAY ROSEMOUNT MN 550684413 16263 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 293 021142037003 THOMAS Q DREYER 16272 FERNANDO WAY ROSEMOUNTMN 55068 16272 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 294 021142037002 DONALD ROSS 16281 FERNANDO WAY ROSEMOUNTMN 550684413 16281 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 295 021142037003 ERIN STEMIG 16290 FERANDO WAY ROSEMOUNT MN 55068 16290 FERNANDO WAY RESIDENTIAL I $4,471.51 54,47LM 296 021142037002 RANDY D &KARAL DRESCHER 16299 FERNANDO WAY ROSEMOUNT MN 550684413 16299 FERNANDO WAY RESIDENTIAL I 94,471.51 $4,471.51 297 021142037003 MICHAEL P & STEPHANI GERARD 16308 FERNANDO WAY ROSEMOUNTMN 55068 -1469 16308 FERNANDO WAY RESIDENTIAL 1 54,471.51 $4,471.51 298 021142037003 CHRISTOPHER D REESE 16326 FERNANDO WAY ROSEMOUNT MN 550684469 16326 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 299 021142037003 MARK A& KATHRYN M PROVOST 16344 FERNANDO WAY ROSEMOUNT MN 55068 -1469 16344 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 300 021142037002 MARK L & BRENDA L MANN 16357 FERNANDO WAY ROSEMOUNT MN 550684403 16357 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 301 021142037003 NHIEM DUC GANG 16362 FERNANDO WAY ROSEMOUNT MN 55068 16362 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 302 021142037002 MICHAEL T MARONEY 16371 FERNANDO WAY ROSEMOUNT MN 550684403 16371 FERNANDO WAY RESIDENTIAL 1 54,471.51 $4,471.51 303 021142037002 STEVEN & ANN SERAFINA 16381 FERNANDO WAY ROSEMOUNT MN 55068 -1403 1 16381 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 304 021142037003 BRET J &LISBETH A ADAMS 16391 FERNANDO WAY ROSEMOUNT MN 55068 16391 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 305 021142037003 CHERYL MARIEBONN 16401 FERNANDO WAY ROSEMOUNT MN 550684451 16401 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,47LM 306 021142035006 GREG T & BETH R BERGACKER 13080 AKRON AVE ROSEMOUNT MN 55068 16411 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 307 021142037001 DENNIS & EVA M BRASELMAN 16420 FERNANDO WAY ROSEMOUNT MN 55068 16420 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 308 021142035006 FREDDIE R &MELISSA BERBERENA 16421 FERNANDO WAY ROSEMOUNT MN 55068 -1451 16421 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 Preliminary Assessment Roll WSB P-Jec& 20145 &eetRe construction Project R —txoct Proposed Reidmdal Pet Uuit Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Adding, Restdmttal Pm Uuit Ass ®smmtRate: 92,166.96 Reviaed. 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Fai,Ween Avenue, Fantasia Avenge, Farcry Way, Fernand, Avenue, Fernando WU, Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FkgslaffWav, Fo"ge Avenge, Lower 161sts&ee4 161. S&-4 162.d S&ee6163rd Street, 164& S&eet, Lower 169th Stree 4 169th S &eef, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 Gearge[awn Way, I70th S&e4 I70th Court WSB Pr jectNo, 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 309 021142037001 JAMES P & SANDRA NOKLEBY 16430 FERNANDO WAY ROSEMOUNTMN 55068 -1412 16430 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 310 021142035002 BILL & LISA BAKER 16440 FERNANDO WAY ROSEMOUNT MN 55068 -1425 16440 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 311 021142035003 FRANK J & THERESA L KOV ARIK 16450 FERNANDO WAY ROSEMOUNT MN 55068 -1425 16450 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 312 021142035006 TIMOTHY TICHICH 16451 FERNANDO WAY ROSEMOUNT MN 55068 16451 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 313 021142035003 TERRY E & FORT L ROSEL 16460FERNANDOWAY ROSEMOUNTMN 55068 -1425 16460 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 314 021142035005 JACK W & CINDY METCALF 16461 FERNANDO WAY ROSEMOUNT MN 55068 -1420 16461 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 315 021142035003 SECRETARY OF HUD 4400 WILL ROGERS PKWY SUITE 300 OKLAHOMACITYOK 73108 16470 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 316 021142035005 TERRENCE.B DALY 16471 FERNANDO WAY ROSEMOUNTMN 55068 -1420 16471 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 317 021142035003 JOHN J& PATRICIA M CIHUNKA 16480 FERNANDO WAY ROSEMOUNTMN 55068 -1425 16480 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 318 021142035005 TERENCE T & MINYO M JOHNSON 16481 FERNANDO WAY ROSEMOUNT MN 55068 -1420 16481 FERNANDO WAY RESIDENTIAL 1 $4,471.51 54,471.51 319 021142035003 LUIS G AYALA 16490 FERNANDO WAY ROSEMOUNT MN 55068 -1425 16490 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 320 021142035005 DENNIS & KAREN E GUDIM 16491 FERNANDO WAY ROSEMOUNT MN 55068 -1420 16491 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 321 021142035003 PETER E & MARSHA DANIELSON 16500 FERNANDO WAY ROSEMOUNT MN 55068 -1450 16500 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 322 021142035005 JAMES & JUDITH A MEYER 16501 FERNANDO WAY ROSEMOUNTMN 55068 -1449 16501 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 323 021142035003 GLENN W POLLACK 16510 FERNANDO WAY ROSEMOUNT MN 55068 -1450 16510 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 324 021142035005 WILLIAM R KNAEBLE 16511 FERNANDO WAY ROSEMOUNT MN 55068 16511 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 325 021142053003 JAMES P & ROSANN SOWADA 16520 FERNANDO WAY ROSEMOUNTMN 55068 -1450 16520 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 326 021142035005 WILLIAM LEE GILBERTSON 16521 FERNANDO WAY ROSEMOUNT MN 55068 -1449 16521 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 327 021142053003 ALAN G & JUDITH HIGGINS 16530 FERNANDO WAY ROSEMOUNT MN 55068 -1450 16530 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 328 021142053003 JAMES L & LEANN C THOMPSON 16540 FERNANDO WAY ROSEMOUNTMN 55068 -1450 16540 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 329 021142053003 DOMONIC NELSON 16550 FERNANDO WAY ROSEMOUNTMN 55068 16550 FERNANDO WAY RESIDENTIAL 1 $4,471.51 $4,471.51 330 021142035010 JAMES E &KAREN KBECKER 16392 FINDLAY WAY ROSEMOUNT MN 55068 -1406 16392FINDLAYWAY COMMERCIAL 1 $4,471.51 $4,471.51 331 021142035006 BILL J& SANDRA RLUCIER 16413 FINDLAY ROSEMOUNTMN 55068 -1440 16413 FINDLAY WAY RESIDENTIAL 1 $4,471.51 $4,471.51 332 021142035006 LAWRENCE G & LINDA HIRDLER 16423 FINDLAY WAY ROSEMOUNT MN 55068 -1440 16423FINDLAYWAY RESIDENTIAL 1 S4,471.51 $4,471.51 333 021142031006 FAYEENELSON 6021162ND STW ROSEMOUNTMN 55068 -1332 6021162ND STW RESIDENTIAL 1 $4,471.51 $4,471.51 334 021142031006 CORBETT V BERG 6039 162ND STW ROSEMOUNT MN 55068 -1332 6039 162ND ST W RESIDENTIAL 1 $4,471.51 $4,471.51 335 021142031006 STEVEN & DIANE CARPENTER 6057 162ND ST W ROSEMOUNT MN 55068 -1332 6057 162ND ST W RESIDENTIAL 1 54,471.51 $4,471.51 336 021142031006 PETER & KRISTI M LAWLESS 6075 162ND STW ROSEMOUNT MN 55068 -1332 6075 162ND ST W RESIDENTIAL 1 $4,471.51 $4,471.51 337 021142031006 JOSEPH P CSEDO 6093 162ND STW ROSEMOUNT MN 55068 -1332 6093 162ND ST W RESIDENTIAL 1 $4,471.51 $4,471.51 338 021142031006 DANIEL G & DAWN A PETERSON 6111162ND STW ROSEMOUNT MN 55068 -1332 6111162ND STW RESIDENTIAL 1 $4.471.51 $4,471.51 339 021142031006 MICHAEL J & HEIDI A FOLLMER 6129162ND ST ROSEMOUNTMN 55068 -1330 6129 162ND ST W RESIDENTIAL I $4,471.51 $4,471.51 340 021142031006 MARK TUCKER 6147 162ND ST ROSEMOUNT MN 55068 -1330 6147 162ND ST W RESIDENTIAL 1 $4,471.51 $4,471.51 341 021142031006 M HOWARD & JUDY HOWELL 6165 162ND ST W ROSEMOUNT MN 55068 -1330 6165 162ND ST W RESIDENTIAL 1 54,471.51 $4,471.51 342 021142031009 MATTHEW T & NICOLE HILGARDNER 6180 162ND STW ROSEMOUNTMN 55068 -1327 6180 162ND ST W RESIDENTIAL 1 54,471.51 $4,471.51 343 021142031005 STEVEN J &TAMMY JOHNSON 6183162ND STW ROSEMOUNTMN 55068 -1330 6183162ND STW RESIDENTIAL 1 54,471.51 $4,471.51 344 021142031005 TODD J & CONNIE K AALTO 6201 162ND ST W ROSEMOUNT MN 1 55068 -1329 6201 162ND ST W RESIDENTIAL 1 54,471.51 $4,471.51 345 021142033008 CYRIL F & DONNA SAUNDERS 6231162ND STW ROSEMOUNT MN 55068 -1466 6231162ND ST W RESIDENTIAL 1 $4,471.51 $4,471.51 346 021142033008 MICHAEL LIGGETT 6251 162ND ST W ROSEMOUNTMN 55068 -1466 6251162ND ST W RESIDENTIAL 1 $4,471.51 $4,471.51 347 021142033009 ROSANNE GRACE RIENDEAU 6260162ND ST ROSEMOUNT MN 55068 -1427 6260162ND STW RESIDENTIAL 1 $4,471.51 $4,471.51 348 021142033008 MICHAEL SHELLICKSON 6271 162ND ST W ROSEMOUNT MN 55068 -1466 6271162ND STW RESIDENTIAL 1 34,471.51 $4,471.51 349 021142033008 SCOTT & TARYN BUCKNER 6291 162ND ST ROSEMOUNT MN 55068 -1466 6291162ND STW RESIDENTIAL 1 $4,471.51 $4,471.51 350 021142033007 WILLIAM & MARYANNE DOERFLER 6301162ND ST W ROSEMOUNT MN 55068 6301162ND STW RESIDENTIAL 1 $4,471.51 $4,471.51 351 021142033008 DOYLE C JR PIPER 6320 162ND STW ROSEMOUNT MN 55068 -1417 6320 162ND ST W RESIDENTIAL 1 $4,471.51 1 $4,471.51 352 021142033007 TRICIA & CHASE WILLIAMS 6321 162ND ST W ROSEMOUNT MN 55068 -1465 6321162ND STW RESIDENTIAL 1 1 $4,471.51 1 $4,471.51 Preliminary Assessment Roll WSB P-Jecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Addition RAdmtial Pm Uuit AssessmmtRate: 52,166.96 Reviaed. 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Fernando Wary Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161sts& -4161. S&-4 162.d Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSB Pr jectNo, 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 353 021142033008 ANATOLIY V & TATYANA SIRUK 6340 162ND ST W ROSEMOUNT MN 55068 6340 162ND ST W RESIDENTIAL 1 $4,471.51 $4,471.51 354 021142033007 DAVID A & CHERYL A GRAMS 6341 162ND ST W ROSEMOUNT MN 55068 -1465 6341 162ND STW RESIDENTIAL 1 $4,471.51 $4,471.51 355 021142031004 KATHRYNAVAS UEZ 6098161STST ROSEMOUNT MN 55068 -131 _ 6098161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 356 021142031008 JOHN F& CHRISTINA M JAEGER 6165161ST STW ROSEMOUNTMN 55068 -1335 6165161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 357 021142033005 STEPHEN R &SHELLEY SABLE 6245161ST ST ROSEMOUNT MN 55068 -1248 6245161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 358 021142033004 CHRISTOPHER J GROSS 6325161STSTW ROSEMOUNT MN 55068 -1206 6325161ST ST RESIDENTIAL 1 $4,471.51 $4,471.51 359 021142031009 TODD A & DEANNE L PETERSEN 6021 161ST ST W ROSEMOUNT MN 55068 -1337 6021 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 360 021142031004 TIMOTHY &DAWN BORGSTAHL 6026161ST STW ROSEMOUNT MN 55068 -1312 6026161ST STW RESIDENTIAL 1 $4,471.51 $4,471.51 361 021142031009 ROBERT P & ARLENE A WIESNER 6039 161ST ST W ROSEMOUNT MN 55068 -1337 6039 161ST STW RESIDENTIAL 1 $4,471.51 $4,471.51 362 021142031004 TIMOTHY E RADKE 6044161ST STW ROSEMOUNTMN 55068 6044161ST STW RESIDENTIAL 1 S4,471.51 54,471.51 363 021142031009 TERESAANIELSEN 6057 16 1 ST STW ROSEMOUNT MN 55068 -1337 6057161ST STW RESIDENTIAL 1 54,471.51 $4,471.51 364 021142031004 CHRIS W & AIMEE C SIMDORN 6062 161ST STW ROSEMOUNT MN 55068 -1312 6062 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 365 021142031008 CHAD L & CYNTHIA BLOCH 6075 161ST STW ROSEMOUNTMN 550684337 6075 161ST ST W RESIDENTIAL 1 $4.471.51 $4,471.51 366 021142031004 JON W &DEBRA L PIETERS 6080 161ST ST W ROSEMOUNTMN 55068 6080 161ST STW RESIDENTIAL 1 $4.471.51 $4,471.51 367 021142031008 GRANT W MOHWINKEL 6093 161ST ST W ROSEMOUNTMN 55068 -1337 6093 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 368 021142031008 ROBERT & AUDREY WEILER 6111161ST ST W ROSEMOUNT MN 550684335 6111161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 369 021142031004 TODD M KIRCHGATTER 6116 16 1 ST STW ROSEMOUNTMN 55068 -1336 6116161ST STW RESIDENTIAL 1 $4,471.51 $4,471.51 370 021142031008 MARKA &RHONDA D PEARL 6129 16 1 ST STW ROSEMOUNT MN 55068 -1335 6129161STSTW RESIDENTIAL 1 $4,471.51 $4,471.51 371 021142031005 ERIC M BRAUN 6134 161ST STW ROSEMOUNT MN 55068 6134 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 372 021142031008 PAUL MANSER 6147 161ST ST W ROSEMOUNTMN 55068 -1335 6147 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 373 021142031005 JEFFREY GOAR 6152 161ST ST W ROSEMOUNTMN 55068 -1336 6152 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 374 021142031005 MERON &MELKA WOLDE 6170161ST STW ROSEMOUNTMN 55068 6170161ST STW RESIDENTIAL 1 $4,471.51 $4,471.51 375 021142031008 LISA A DALLMAN 6183 161ST ST W ROSEMOUNTMN 55068 -1335 6183161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 376 021142031005 DARREN I& MICHELLE. LAWRENCE 6188161ST STW ROSEMOUNTMN 55068 6188161STSTW RESIDENTIAL 1 $4,471.51 $4,471.51 377 021142031008 RYAN JOHN THORSON 6201 161ST ST W ROSEMOUNT MN 55068 -1333 6201 161ST STW RESIDENTIAL 1 54,471.51 $4,471.51 378 021142031005 MERKAN CORPORATION 706 ROBERT ST S SAINT PAUL MN 55107 -2948 6206 161ST STW RESIDENTIAL 1 54,471.51 $4,471.51 379 1 021142031008 DOUGLAS A & CHERYLE THESING 6219 161ST ST W ROSEMOUNT MN 550684333 6219 161ST ST W RESIDENTIAL 1 54,471.51 $4,471.51 380 021142031005 DEBRA ANN CAPENER 6224161ST AVE ROSEMOUNT MN 55068 6224161ST STW RESIDENTIAL 1 54,471.51 $4,471.51 381 021142033004 BARBARA WALKER 6265161ST STW ROSEMOUNTMN 55068 -1248 6265161STSTW RESIDENTIAL 1 $4,471.51 $4,471.51 382 021142033007 MARK &PAMELA ROSENOW 6270161ST STW ROSEMOUNTMN 55068 -1250 6270161ST STW RESIDENTIAL 1 $4.471.51 $4,471.51 383 021142033004 JERRY M & JARI J LANIER 6285 161ST ST W ROSEMOUNT MN 550684248 6285 161ST ST W RESIDENTIAL I 54,471.51 $4,471.51 384 021142033007 EARLING KING & BETH BOO 6290 161ST ST W ROSEMOUNT MN 550684250 6290 161ST ST W RESIDENTIAL 1 54,471.51 $4,471.51 385 021142033004 RICHARD J & MARY L HUISMANN 6305 161ST ST W ROSEMOUNT MN 550684206 6305 161ST STW RESIDENTIAL 1 $4,471.51 $4,471.51 386 021142033007 DAVID N & MARSHA M GAWBOY 6310 161ST ST W ROSEMOUNT MN 550684247 6310 161ST ST W RESIDENTIAL 1 $4,471.51 $4,471.51 387 021142033007 DAVIDC & JUDY L KANER 6330161ST STW ROSEMOUNTMN 55068 -1247 6330161ST STW RESIDENTIAL 1 $4,471.51 $4,471.51 388 021142033007 MITCHELL & TAMMY NEWBERRY 16133 FINCH AVE ROSEMOUNTMN 55068 -1234 16133 FINCH AVE RESIDENTIAL 1 $4,471.51 $4,471.51 389 021142031005 DARIN P &LORI M PEARSON 16144 FINCH AVE ROSEMOUNT MN 55068-1236 16144 FINCH AVE RESIDENTIAL 1 $4,471.51 $4,471.51 390 021142033009 DANIEL CVINGE 16215 FINCH AVE ROSEMOUNTMN 55068 -1422 16215 FINCH AVE RESIDENTIAL 1 $4,471.51 $4,471.51 391 021142031005 ANDRED &MARLAD RUSH 16220 FINCH AVE ROSEMOUNTMN 55068 -1423 16220 FINCH AVE RESIDENTIAL 1 $4,471.51 $4,471.51 392 021142031002 DAVID& LINDA CHMIELEWSKI 16200 FANTASIA AVE ROSEMOUNT MN 55068 -1458 16200 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 393 021142031001 JOHN T & CINDY WAGGONER 16201 FANTASIA ROSEMOUNT MN 55068 -1457 16201 FANTASIA AVE RESIDENTIAL 1 54,471.51 $4,471.51 394 021142031002 JOHN D &KIMA ZSCHUNKE 16217 FANTASIA AVE ROSEMOUNTMN 55068 -1457 1 16217 FANTASIA AVE I RESIDENTIAL 1 $4,471.51 $4,471.51 395 021142031002 ERIC A & KATHLEEN R CRAM 8871163RD ST W LAKEVILLE MN 55044 1 16218 FANTASIA AVE RESIDENTIAL 1 $4,47L51 $4,471.51 396 021142031001 DAVID NELSON 16235 FANTASIA AVE ROSEMOUNT MN 55068m14571 16235 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 Preliminary Assessment Roll WSB P-Jecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Addition RAdmtial Pm Uuit AssessmmtRate: 52,166.96 Reviaed. 1012112013 Cedar IBghlaods 5th Addifian Resideofial Per Unit Assessmmt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Fernando WU, Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161stHhee4 161st S&-4 162.d Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSB Pr jectNo, 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 397 021142031002 ROBIN LEE SELVIG 16236 FANTASIA AVE ROSEMOUNT MN 55068 -1458 16236 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 398 021142031001 CORY S ENGLUND 16253 FANTASIA AVE ROSEMOUNT MN 55068 -1457 16253. FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 399 021142031002 MICHAEL JAMES BEAVER 16254 FANTASIA ROSEMOUNT MN 55068 16254 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 400 021142037004 WILLIAM J SCHAEFER 16271 FANTASIA AVE ROSEMOUNT MN 55068 -1457 16271 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 401 021142037005 MABEL &JANA A NORLAND 16272 FANTASIA AVE ROSEMOUNTMN 55068 16272 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 402 021142037004 JAMES E& KATHYRN SARTELL 16289 FANTASIA AVE ROSEMOUNT MN 55068 -1457 16289 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 403 021142037005 BEZEAMLAKAKIDANE 16290 FANTASIA AVE ROSEMOUNT MN 55068 -1458 16290FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 404 021142037004 PATRICK C &DEBORA DEVEREAUX 16307 FANTASIA AVE ROSEMOUNT MN 55068 -1428 16307 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 405 021142037005 TIMOTHY J &DENISE M BAKER 16308 FANTASIA AVE ROSEMOUNT MN 55068 -1456 16308 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 406 021142037004 WADE A & KE14BERLY V BERGLAND 16325 FANTASIA AVE ROSEMOUNTMN 55068 16325 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 407 021142037004 STEPHEN C & AIMEE PETER 16343 FANTASIA AVE ROSEMOUNT MN 55068 -1428 16343 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 408 021142037005 MARC L GINGERICH 16344 FANTASIA AVE ROSEMOUNT MN 55068 16344 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 409 021142037004 SCOTT SOIKA 49694 FANTASIA AVE ROSEMOUNT MN 55068 -1428 16361 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 410 021142037005 BRIAN D PETERSON PO BOX 21251 EAGAN MN 55121 16362 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 411 021142037003 DALE A& VICTORIA L JOHNSON 16379 FANTASIA AVE ROSEMOUNT MN 55068 -1428 16379 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 412 021142037005 RILEY & KATIJA A PETERSON 16380 FANTASIA AVE ROSEMOUNT MN 55068 16380 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 413 021142037005 ADAM& MELISSAHAVILAND 16398 FANTASIA AVE ROSEMOUNT MN 55068 -1456 16398 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 414 021142037003 PHILIP S &PAULA JFRENCH 16405 FANTASIA AVE ROSEMOUNT MN 55068 16405 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 415 021142037005 MARIAN A STANKOSKI 16406 FANTASIA AVE ROSEMOUNT MN 55068 -1456 16406 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 416 021142037006 MICHAEL HMORK 16414. FANTASIA AVE ROSEMOUNT MN 55068 -1455 16414 FANTASIA AVE RESIDENTIAL 1 $4,471.51 $4,471.51 417 021142037005 GLENN L &BETH ANN T GROB 16326 FANTASIA AVE ROSEMOUNT MN 550684456 16326 FANTASIA AVE S RESIDENTIAL 1 $4,471.51 $4,471.51 418 021142037000 JOHN W & ROBYN J ROSE 16377 FARCRY WAY ROSEMOUNT MN 55068 -1410 16377 FARCRY WAY RESIDENTIAL 1 $4,471.51 $4,471.51 419 021142037000 NANCY K STEVENS 16393 FARCRY WAY ROSEMOUNTMN 55068 -1410 16393 FARCRY WAY RESIDENTIAL 1 $4,471.51 $4,471.51 420 021142037000 BARBARA ANN BROCKMAN 16409 FARCRY WAY ROSEMOUNT MN 55068 -1414 16409 FARCRY WAY RESIDENTIAL 1 $4,471.51 $4,471.51 421 021142037000 SHAWN MARIE APP HEINZEN 16425 FARCRY WAY ROSEMOUNT MN 55068 -1414 16425 FARCRY WAY RESIDENTIAL 1 $4,471.51 $4,471.51 422 021142037000 GARY A &JUDDHHALLAWAY 16441 FARCRY WAY ROSEMOUNTMN 550684414 16441 FARCRY WAY RESIDENTIAL 1 $4,471.51 $4,471.51 423 021142031003 ANITA WRIGHTNINNEMAN WRIGHT- KNIEFEL 16036 FAIRGREEN ROSEMOUNT MN 550684311 16036 FAIRGREEN RESIDENTIAL 1 $4,471.51 $4,471.51 424 021142031003 JOEL &LISA TAKKINEN 12832 APPLE VIEW LANE BURNSVILLE MN 55337 16108 FAIRGREEN RESIDENTIAL 1 54,471.51 $4,471.51 425 021142037004 PAULETTE KLECKLEY 16361 FAIRGREEN AVE ROSEMOUNT MN 55068 4319 16361 FAIRGREEN RESIDENTIAL 1 $4.471.51 $4,471.51 426 021142031002 TIFFANY M &PETER MASK 16018 FAIRGREEN AVE ROSEMOUNT MN 55068 4311 16018 FAIRGREENAVE RESIDENTIAL 1 $4,471.51 $4,471.51 427 021142031003 J MICHAEL & KATHLEEN PETERSON 16072 FAIRGREEN AVE ROSEMOUNT MN 550684311 16072 FAIRGREEN AVE RESIDENTIAL I $4,471.51 $4,471.51 428 021142031003 MARTIN C HEMME 16090 FAIRGREEN AVE ROSEMOUNT MN 55068 16090 FAIRGREEN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 429 021142031003 DEBORAHELUCK 16126 FAIRGREEN AVE ROSEMOUNTMN 55068 -1314 16126 FAIRGREEN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 430 021142031003 KATHRYN L STRINGER 16144 FAIRGREEN AVE ROSEMOUNT MN 550684314 16144 FAIRGREEN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 431 021142031003 TIM &KIM LITTLE 16162 FAIRGREEN AVE ROSEMOUNT MN 550684314 16162 FAIRGREEN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 432 021142031003 MARGARET SANZ 16180 FAIRGREEN AVE ROSEMOUNT MN 550684314 16180FAIRGREENAVE RESIDENTIAL 1 $4,471.51 $4,471.51 433 021142031003 DOUGLASRVOGEL 16198 FAIRGREEN AVE ROSEMOUNT MN 550684314 16198 FAIRGREEN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 434 021142031004 DANIEL ALAN SOUTHERTON 16216 FAIRGREEN AVE ROSEMOUNTMN 55068 -1323 16216 FAIRGREEN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 435 021142031002 STEVEN L FILERS 16217 FAIRGREEN AVE ROSEMOUNT MN 550684322 16217 FAIRGREEN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 436 021142031004 JEROME.I &JODEE A JACOBS 16234 FAIRGREEN AVE ROSEMOUNT MN 550684323 16234FAIRGREENAVE RESIDENTIAL 1 $4,471.51 $4,471.51 437 021142031002 PAUL A & RHONDA STEIN 16235 FAIRGREEN AVE ROSEMOUNT MN 550684322 16235 FAIRGREEN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 438 021142031002 CHRISTOPHERW &ANGEKUTZ 16253 FAIRGREEN AVE LAKEVILLEMN 55044 16253FAIRGREENAVE RESIDENTIAL 1 $4,471.51 $4,471.51 439 021142031004 THOMAS T LORANGER 16270 FAIRGREEN AVE ROSEMOUNTMN 55068 -1323 16270 FAIRGREENAVE RESIDENTIAL 1 $4,471.51 $4,471.51 440 021142031002 1 MOHAMED& KAUSARBACHELANI 16271 FAIRGREEN AVE ROSEMOUNTMN 55068 -1322 16271 FAIRGREENAVE RESIDENTIAL 1 $4,471.51 $4,471.51 Preliminary Assessment Roll WSB P-Jec& 2014 S &eetReconstrucaon Project R —txoct Proposed Re idmdal Pet Uuit Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Adding, RAdmttal Pm Uuit Ass ®smmtRate: 92,166.96 Reviaed: 1012112013 Cedar Dighlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Fai,Ween Avenue, Fantasia Avenge, Farcry Way, Fernand, Avenue, Femando WU, Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FkgslaffWav, Fo"ge Avenge, Lower 161sts&ee4 161. S&-4 162.d S&ee6163rd Street, 164& S&eet, Lower 169th Stree 4 169th S &eef, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 Gearge[awn Way, I70th S&e4 I70th Court WSBPr jctNo.: 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 441 021142037006 CASEY ALLAN PRESTEGARD 16288 FARIGREEN AVE ROSEMOUNTMN 55068 -1323 16288FADLGREENAVE RESIDENTIAL 1 $4,471.51 $4,471.51 442 021142037005 KYLE &LYNN GILLETT 16289 FAIRGREEN AVE ROSEMOUNT MN 55068 -1322 16289FADLGREENAVE RESIDENTIAL 1 $4,471.51 $4,471.51 443 021142037006 GUSTAVO RODRIGUEZ ORTIZ 16306FAIRGREENAVE ROSEMOUNT MN 55068 -1321 16306FAIRGREENAVE RESIDENTIAL 1 $4,471.51 $4,471.51 444 021142037004 AMY RTIDD 16307 FAIRGREEN AVE ROSEMOUNT MN 55068 -1319 16307 FAIRGREEN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 445 021142037006 PAUL & GINAMEINHARDT 16324 FAIRGREEN AVE ROSEMOUNT MN 55068 16324FAIRGREENAVE RESIDENTIAL 1 $4,471.51 $4,471.51 446 021142037004 DENISE SMALLEN 16325 FAIRGREEN AVE ROSEMOUNT MN 55068 -1319 16325 FAIRGREEN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 447 021142037004 TODDWBISHOP 16343 FAIRGREEN AVE ROSEMOUNT MN 55068 -1319 16343 FAIRGREEN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 448 021142031003 BOUNMY PRAXAYA 16054 FAIRGREEN AVE ROSEMOUNT MN 55068 16054 FAIRGREEN AVE S RESIDENTIAL 1 $4,471.51 $4,471.51 449 021142031004 NIBENM SINGH 16252 FAIRGREEN AVE S ROSEMOUNTMN 55068 -1323 16252 FAIRGREEN AVE S RESIDENTIAL 1 $4,471.51 $4,471.51 450 021142013001 SCOTT L &KAREN M JACOBSON 16207 EXCELSIOR CIR ROSEMOUNT MN 55068 -1361 16207 EXCELSIOR CIR RESIDENTIAL 1 S4,471.51 $4,471.51 451 021142013001 MICHAEL AMACH 16211 EXCELSIOR CIR ROSEMOUNT MN 55068 -1361 16211 EXCELSIOR CIR RESIDENTIAL 1 $4,471.51 $4,471.51 452 021142015000 KENDALL & MICHELE SNARE 16215 EXCELSIOR CIR ROSEMOUNTMN 55068 -1361 16215 EXCELSIOR CIR RESIDENTIAL 1 $4,471.51 $4,471.51 453 021142015000 FEDERAL NATIONAL MORTGAGE ASSOCIATION 14221 DALLAS PKWY STE 1000 DALLAS IX 75254 -2916 16219 EXCELSIOR CIR RESIDENTIAL 1 $4.471.51 $4,471.51 454 021142015000 DAVID I& RUTH MILLER 16223 EXCELSIOR CIR ROSEMOUNTMN 55068 -1361 16223 EXCELSIOR CIR RESIDENTIAL 1 $4,471.51 $4,471.51 455 021142015000 JUSTIN HOLMAN 16227 EXCELSIOR CIR LAKEVILLE MN 55044 16227 EXCELSIOR CIR RESIDENTIAL I $4,471.51 $4,471.51 456 021142013002 JUSTIN R CARLSON 16134 EXCELSIOR CT ROSEMOUNT MN 55068 16134 EXCELSIOR CT RESIDENTIAL 1 $4,471.51 $4,471.51 457 021142013002 TIMOTHY J& ESTHER M LOGELIN 16136 EXCELSIOR CT ROSEMOUNT MN 55068 -1362 16136 EXCELSIOR CT RESIDENTIAL 1 $4,471.51 $4,471.51 458 021142013002 ROBERT W & SANDRA K BUCKINGHAM 16138 EXCELSIOR CT ROSEMOUNT MN 550684362 16138 EXCELSIOR CT RESIDENTIAL 1 54,471.51 $4,471.51 459 021142013002 LARRY &JANET DAMMANN 16140 EXCELSIOR CT ROSEMOUNT MN 550684362 16140 EXCELSIOR CT RESIDENTIAL 1 $4,471.51 $4,471.51 460 021142013002 DON MARTEL 16142 EXCELSIOR CT ROSEMOUNT MN 55068 16142 EXCELSIOR CT RESIDENTIAL 1 $4,471.51 $4,471.51 461 021142013002 JUAN F GUZMAN MORALES 16144 EXCELSIOR CT ROSEMOUNTMN 55068 -1362 16144 EXCELSIOR CT RESIDENTIAL 1 $4,471.51 $4,471.51 462 021142013000 PATRICK OWENS 16023 EXCELSIOR DR ROSEMOUNT MN 550684349 16023 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 463 021142013000 THOMAS D &LYNDA S MIF.LKE 16039 EXCELSIOR DR ROSEMOUNT MN 55068 -1349 16039 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 464 021142013000 ROGERNELSON 16055 EXCELSIOR DR ROSEMOUNT MN 550684349 16055 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 465 021142013001 AMANDAHANSON 16064 EXCELSIOR DR ROSEMOUNTMN 55068 16064 EXCELSIOR DR RESIDENTIAL 1 54,471.51 $4,471.51 466 021142013000 DANIEL W &BETTY J TOSIER 16071 EXCELSIOR DR ROSEMOUNT MN 55068 -1349 16071 EXCELSIORDR RESIDENTIAL 1 $4,471.51 $4,471.51 467 1 021142013001 1 MAWUENA KPADE KOFFI 16078 EXCEL SIOR DR ROSEMOUNTMN 55068 -1358 1 16078 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 468 021142013000 GARYAMICKELSON 16085 EXCELSIOR DR ROSEMOUNT MN 55068 16085 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 469 021142013002 HEIDI M &SAMUEL RHENKE 16096 EXCELSIOR DR ROSEMOUNT MN 55068 4358 16096 EXCELSIOR DR RESIDENTIAL 1 $4.471.51 $4,471.51 470 021142013000 TIMOTHY BEACH 16103 EXCELSIOR DR ROSEMOUNTMN 55068 16103 EXCELSIOR DR RESIDENTIAL 1 $4.471.51 $4,471.51 471 021142013002 JEFFREYT & TINA L BUNNISS 16108 EXCELSIOR DR ROSEMOUNT MN 550684358 16108 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 472 021142013000 JAMES L & NANETTE G HEINLE 16115 EXCELSIOR DR ROSEMOUNTMN 55068 -1360 16115 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 473 021142013002 BRIAN J & BRENDA HORAK 16122 EXCELSIOR DR ROSEMOUNT MN 550684358 16122 EXCELSIOR DR RESIDENTIAL 1 54,471.51 $4,471.51 474 021142013000 JEFFREY & THERESA BEYER 16131 EXCELSIOR DR ROSEMOUNT MN 550684360 16131 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 475 021142013000 GARYKBAUM 16147 EXCELSIOR DR ROSEMOUNTMN 55068 -1360 16147 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 476 021142013001 J MARK &PATRICIA HEGGE 16163 EXCELSIOR DR ROSEMOUNTMN 55068 -1360 16163 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 477 021142013002 DANA M BRENNA 16174 EXCELSIOR DR LAKEVB,LEMN 55068 16174 EXCELSIOR DR RESIDENTIAL 1 54,471.51 $4,471.51 478 021142013001 CAROL L KISSELL 16177 EXCELSIOR DR ROSEMOUNTMN 55068 -1360 16177 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 479 021142013003 LYLE &KATHYLUPPES 16188EXCELSIORDR ROSEMOUNT MN SS068-N 16188 EXCEL SIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 480 021142013001 ERIC PELTO 16191 EXCELSIOR DR ROSEMOUNT MN SS068 -1360 16191 EXCELSIOR DR RESIDENTIAL 1 94,471.51 $4,471.51 481 021142013001 PABLO &BIANCABFLORES 16203 EXCEL SIORDR ROSEMOUNTMN 55068 -1342 16203 EXCELSIORDR RESIDENTIAL 1 $4,471.51 $4,471.51 482 021142013003 ANTHONY K &SHERI L RONCHAK 16210 EXCELSIOR DR 1 ROSEMOUNT MN I 55068 -1347 1 16210 EXCELSIOR DR RESIDENTIAL 1 1 54,471.51 $4,471.51 483 021142013001 WB.LIAMB &MARILYN THOMAS 16231 EXCELSIOR DR ROSEMOUNT MN 55068 -1342 16231 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 484 021142013004 JOHN N& MARY LEE THOMPSON 16232 EXCELSIOR DR ROSEMOUNT MN 1 55068 -1347 16232 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 Preliminary Assessment Roll WSB P-Jecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Addition RAdmtial Pm Uuit AssessmmtRate: 92,166.96 Reviaed. 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Fernando WU, Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161stShee4 161. S&-4 162.d Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSBPr jectNo, 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 485 021142013001 SALLY E HOUWMAN 16235 EXCELSIOR DR ROSEMOUNT MN 55068 -1342 16235 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 486 021142013004 TODD A ALBERS 16236 EXCELSIOR DR ROSEMOUNTMN 55068 -1347 16236 EXCELSIOR DR RESIDENTIAL 1 54,471.51 $4,471.51 487 021142013004 UT THI IRAN 16237 EXCELSIOR DR ROSEMOUNT MN 55068 16237 EXCELSIOR. DR RESIDENTIAL 1 $4,471.51 $4,471.51 488 021142013004 ERIKR &KELSEYRHOFF 16238 EXCELSIOR DR ROSEMOUNT MN 55068 16238 EXCELSIOR. DR RESIDENTIAL 1 $4,471.51 $4,471.51 489 021142013004 JEFFREY A & MICHELE ROBINSON 16239 EXCELSIOR DR ROSEMOUNT MN 55068 16239 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 490 021142013004 REBECCA BEYAN 16240 EXCELSIOR DR ROSEMOUNT MN 55068 -1347 16240 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 491 021142013004 VRON JONES 16241 EXCELSIOR DR ROSEMOUNTMN 55068 -1342 16241 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 492 021142013004 JENNAREINEMANN 16243 EXCELSIOR DR LAKEVILLE MN 55044 16243 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 493 021142013005 MARGARET L LESLIE 16245 EXCELSIOR DR ROSEMOUNT MN 55068 16245 EXCELSIORDR RESIDENTIAL 1 $4,471.51 $4,471.51 494 021142013005 JOY PETERSON 16247 EXCELSIOR DR ROSEMOUNTMN 55068 -1342 16247 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 495 021142013005 JAY E& PATRICIA T POWELL 16749 EXCELSIOR DR ROSEMOUNT MN 55068 -1342 16249 EXCELSIOR DR RESIDENTIAL 1 $4,471.51 $4,471.51 496 021142013004 JASONTBRUSKI 16234 EXCELSIOR BLVD ROSEMOUNTMN 55068 16234 EXCELSIOR DR S RESIDENTIAL 1 $4,471.51 $4,471.51 497 021142013003 KURDS R & ERICA L TRIEBENBACH 16040 DODD LN ROSEMOUNT MN 55068 16040 DODD LN RESIDENTIAL 1 $4.471.51 $4,471.51 498 021142013005 LUKE WAGNER 16044DODDLN ROSEMOUNTMN 550684363 16044 DODD LN RESIDENTIAL 1 $4.471.51 $4,471.51 499 021142013005 ROBERT L & MARY T GRAFF 16048 DODD LN ROSEMOUNT MN 55068 16048 DODD LN RESIDENTIAL 1 $4,471.51 $4,471.51 500 021142013003 MARC G GB,LIES 16051 DODD LN ROSEMOUNT MN 550684364 16051 DODD LN RESIDENTIAL 1 $4,471.51 $4,471.51 501 021142013005 DEAN W & SHERYL L BRITTAIN 16052 DODD LANE. ROSEMOUNT MN 1 550684363 16052 DODD IN RESIDENTIAL 1 $4,471.51 $4,471.51 502 021142013005 LLOYD R ABRAHAM 16058 DODD LN ROSEMOUNT MN 550684363 16058 DODD IN RESIDENTIAL 1 $4,471.51 $4,471.51 503 021142013003 WILLIAM EDGAR BECK 16061 DODD LN ROSEMOUNT MN 55068 16061 DODD IN RESIDENTIAL 1 $4,471.51 $4,471.51 504 021142013005 MARK T & MERRB.EE A STIBAL 16064 DODD LN ROSEMOUNT MN 55068 -1363 16064 DODD LN RESIDENTIAL 1 $4,471.51 $4,471.51 505 021142013003 DOUGLAS L& MONICA M HOEPPNER 16071 DODD LN ROSEMOUNTMN 550684364 16071 DODD LN RESIDENTIAL 1 $4,471.51 $4,471.51 506 021142013005 TRISHA M VENNINK 16076 DODD IN ROSEMOUNT MN 55068 16076 DODD IN RESIDENTIAL 1 $4,471.51 $4,471.51 507 021142013003 ROBERT W & LINDA M PAYETTE 16081 DODD LN ROSEMOUNTMN 55068 -1364 16081 DODD LN RESIDENTIAL 1 $4,471.51 $4,471.51 508 021142013005 MICHAEL E BUDZINSKI 16088 DODD LN ROSEMOUNT MN 550684363 16088 DODD LN RESIDENTIAL 1 $4,471.51 $4,471.51 509 021142013006 MARIA SUSAN VALERA MURRAY 16094DODDLN ROSEMOUNT MN 550684363 16094 DODD LN RESIDENTIAL 1 $4,471.51 $4,471.51 510 021142013003 DWAYNE M & JULIE A JOHNSON 16095 DODD IN ROSEMOUNT MN 550684364 16095 DODD LN RESIDENTIAL 1 $4,471.51 $4,471.51 511 021142013003 ERIC L & KIMBERLY D RUNNINGEN 16107 DODD LN ROSEMOUNT MN 550684364 16107 DODD LN RESIDENTIAL 1 54,471.51 $4,471.51 512 021142013006 JAMES & BARBARA OLSON 16108 DODD LN ROSEMOUNTMN 550684300 16108 DODD LN RESIDENTIAL 1 $4,471.51 $4,471.51 513 021142013006 JEFFREY M &CHARLENE BRINER 16120 DODD IN ROSEMOUNT SIN 550684300 16120 DODD LN RESIDENTIAL 1 $4.471.51 $4,471.51 514 021142013003 ROBERT D & LAUREN E WEST 16123 DODD LN ROSEMOUNT MN 55068 -1364 16123 DODD IN RESIDENTIAL 1 $4.471.51 $4,471.51 515 021142013006 THOMAS P & ANA M GREGG 16130 DODD LN ROSEMOUNT MN 55068 4300 16130 DODD LN RESIDENTIAL 1 $4,471.51 $4,471.51 516 021142013004 DONALD &ALTHEAMCGEE. 16133 DODD LN ROSEMOUNTMN 550684364 16133 DODD IN RESIDENTIAL 1 $4,471.51 $4,471.51 517 021142013006 CEDRIC & MINNIE P MURPHY 16140 DODD LN ROSEMOUNT MN 550684300 16140 DODD LN RESIDENTIAL 1 $4,471.51 $4,471.51 518 021142013006 JOHN G & KUM IM HERRON 16150 DODD LN ROSEMOUNT MN 550684300 16150 DODD IN RESIDENTIAL 1 $4,471.51 $4,471.51 519 021142013006 KYLE LEE ANDERSON 16160 DODD IN ROSEMOUNT MN 550684300 16160 DODD LN RESIDENTIAL 1 $4,471.51 $4,471.51 520 021142011000 TERESA MACIAS- MONTES 16010 EXCEL WAY ROSEMOUNT MN 550684350 16010 EXCEL RESIDENTIAL 1 $4,471.51 $4,471.51 521 021142011000 JOSEPH A & RONDA L LEECH 16004 EXCEL WAY ROSEMOUNT MN 550684350 16004 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 522 021142013009 RICHARD S HERVIEUX 16005 EXCEL WAY ROSEMOUNT MN 55068 -1350 16005 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 523 021142013008 AJA MARIE MALECK 16013 EXCEL WAY ROSEMOUNT MN 550684350 16013 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 524 021142011000 CHRISTINE ROSE 16014 EXCEL WAY ROSEMOUNT MN 550684350 16014 EXCEL WAY RESIDENTIAL 1 54,471.51 $4,471.51 525 021142011000 AARON C VAUDT 16020 EXCEL WAY ROSEMOUNTMN 55068 16020 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 526 021142013008 KEVIN &AMY STERN 16023 EXCEL WAY ROSEMOUNTMN 55068 16023 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 527 021142011000 SCOTT W &KATRINA M PEARSON 16024 EXCEL WAY ROSEMOUNTMN 55068 -1345 16024 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 528 021142011000 LORI &CRAIGCLARK 16030 EXCEL WAY ROSEMOUNT MN 55068 -1345 16030 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 Preliminary Assessment Roll WSB P-Jecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Addition RAdmtial Pm Uuit AssessmmtRate: 52,166.96 Reviaed. 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Fernando Wary Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161sts& -4161. S&-4 162.d Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSBPr jectNo, 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF FES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 529 021142013008 THY PANN 16031 EXCEL WAY ROSEMOUNT MN 55068 -1345 16031 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 530 021142013007 DENNIS &KAREN BLENIS 16034 EXCEL WAY ROSEMOUNTMN 55068 -1345 16034 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 531 021142013007 ERIC &HAYLEYLONN.UIST 16040 EXCEL WAY ROSEMOUNT MN 55068 -1345 16040 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 532 021142013008 VALENTINE GWELLEM 16041 EXCEL WAY LAKEVILLE MN 55068 16041 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 533 021142013007 MARK K& VIRGINIA M LEHR 16044 EXCEL WAY ROSEMOUNT MN 55068 -1345 16044 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 534 021142013008 TERRY J & PAMELA J WELLER 16049 EXCEL WAY ROSEMOUNT MN 55068 -1341 16049 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 535 021142013007 DENNIS J KOHNER 16050 EXCEL WAY ROSEMOUNT MN 55068 -1324 16050 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 536 021142013007 STEPHEN WOZNIAK 16054 EXCEL WAY ROSEMOUNT MN 55068 16054 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 537 021142013008 PETER D& CATHERINE HIGHMARK 16059 EXCEL WAY ROSEMOUNT MN 55068 -1324 16059 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 538 021142013007 XM TOUA VANG 16060 EXCEL WAY ROSEMOUNT MN 55068 -1324 16060 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 539 021142013007 GARY J FRIES 16064 EXCEL WAY ROSEMOUNT MN 55068 -1324 16064 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 540 021142013008 JEFFREY & CONNIE THEURER 16067 EXCEL WAY ROSEMOUNTMN 55068 -1324 16067 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 541 021142013007 ESIE R KLEIN 16070 EXCEL WAY ROSEMOUNTMN 55068 -1324 16070 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 542 021142013007 IRREVOCABLE SPECIALNEEDS TRUST 1360 PEACH TREE ST NE UNIT 190 ATLANTA GA 30309 16074 EXCEL WAY RESIDENTIAL 1 S4.47L51 $4,471.51 543 021142013008 HOANG D DOAN 16077 EXCEL WAY ROSEMOUNT MN 55068 -1324 16077 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 544 021142013007 BRETT D & SARAH ANNE ANDERSON 16080 EXCEL WAY ROSEMOUNT MN 55068 16080 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 545 021142013006 TROY GOOD 16084 EXCEL WAY ROSEMOUNT MN 55068 16084 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 546 021142013008 BLAIRJ AAKRE 16085 EXCEL WAY ROSEMOUNT MN 55068 -1324 16085 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 547 021142013006 NEIL D & SANDRA L HANDEL 16090 EXCEL WAY ROSEMOUNT MN 55068 -1324 16090 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 548 021142013006 JAMES EBAKKEN 16094 EXCEL WAY ROSEMOUNTMN 55068 -1324 16094 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 549 021142013008 JOSHUAJKUNDERT 16095 EXCEL WAY ROSEMOUNT MN 55068 -1324 16095 EXCEL WAY RESIDENTIAL 1 $4,471.51 $4,471.51 550 031142077007 MERLE L & APRIL M BORK 6520 169TH STW FARMINGTON MN 55024 6520 169TH ST W RESIDENTIAL 1 $4,471.51 54,471.51 551 031142077007 RONALD G & TERESA M DAVIS 6540 169TH ST W FARMINGTON MN 55024 -9401 6540 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 552 031142077005 MICHAEL S OTIS 6555 169TH STW FARMINGTON MN 55024 -9402 6555 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 553 031142077007 MICHAEL A &LESLIE KELZENBERG 13644 PILOT KNOB RD APPLE VALLEY MN 55124 6560 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 554 031142077005 ROBERT J PEEK 6575 169TH STW FARMINGTON MN 55024 6575 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 555 1 031142077007 BERT HOSTETLER 6580 169TH STW FARMINGTON MN 55024 -9401 1 6580 169TH ST W RESIDENTIAL 1 54,471.51 $4,471.51 556 031142077007 DENNIS GEORGE 6590 169TH STW FARMINGTON MN 55024-9401 6590 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 557 031142077005 TRACEY ANN LUEBRS 6595 169TH ST W FARMINGTONMN 55024-9402 6595 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 558 031142077007 STEVEN M & ROBIN R ARENDS 6610 169TH ST FARMINGTON MN 55024-9403 6610 169TH ST W RESIDENTIAL 1 $4.471.51 $4,471.51 559 031142077005 LAWRENCE P & C M KEARNEY 6615 169TH STW FARMINGTON MN 55024 -9404 6615 169TH ST W RESIDENTIAL I 54,47171 $4,471.51 560 031142077005 WILLIAM J JR & GINA NELSON 6625 169TH STW FARMINGTON MN 55024 -9404 6625 169TH ST W RESIDENTIAL I 54,471.51 $4,471.51 561 031142077007 KISSANAK THONGRATSAMY 6630 169TH ST W FARMINGTON MN 55024-9403 6630 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 562 031142077005 CASSANDRA J SKELTON 6645 169TH STW FARMINGTON MN 55024 6645 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 563 031142077007 TYLER & ANN KIRCHNER 6650 169TH ST W FARMINGTON MN 55024 6650 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 564 031142077005 DANIEL L &NORA J ANDERSON 6655 169TH ST W FARMINGTON MN 55024 -9404 6655 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 565 031142077007 ANTHONY J SCHERER 6660 169TH ST W FARMINGTON MN 55024 - 9403 6660 169TH STW RESIDENTIAL 1 $4,471.51 $4,471.51 566 031142077007 JUDY A GLENN 6670 169TH ST W FARMINGTON MN 55024 -9403 6670 169TH ST W RESIDENTIAL 1 $4471.51 $4,471.51 567 031142077006 CASEY B & SALLY A HUTSON 6675 169TH STW FARMINGTON MN 55024-9404 6675 169TH STW RESIDENTIAL 1 $4,471.51 $4,471.51 568 031142077008 DANNY LEE SR MCDOWELL 6680169TH ST W FARMINGTON MN 55024 -9403 6680 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 569 031142077008 DORENE K & TIMOTHY WERZ 6690 169TH STW FARMINGTON MN 55024 -9403 6690 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 570 031142077008 ALEXANDER P & JUDY A MARCHESSAULT 6700 169TH ST W FARMINGTON MN 55024 6700 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 571 031142077008 JOSHUA &ANITAJUNTUNEN 6710169TH STW FARMINGTON MN 55024 -9405 6710169TH STW RESIDENTIAL 1 $4,471.51 $4,471.51 572 031142077003 SHAWN & SARAH ENEZERKA 6545 LOWER 169TH ST W FARMINGTONMN 55024 -8035 6545 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 Preliminary Assessment Roll WSB P-Jecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Addition RAdmtial Pm Uuit AssessmmtRate: 92,166.96 Reviaed. 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Fernando WU, Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161sts& -4161. S&-4 162.d Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSB Pr jectNo, 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 573 031142077003 SHEILA L ENRICH 6565 LOWER 169TH ST W FARMINGTON MN 55024 -8035 6565 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 574 031142077003 PAULETTE L ANDERSON 6585 LOWER 169TH ST W FARMINGTON MN 55024 -8035 6585 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 575 031142077006 TODD R &NICOLE D BROWN 6590 LOWER 169TH ST W FARMINGTONMN 55024 -8037 6590 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 576 031142077003 PETER JOHN GRAFFUNDER 9750230TH ST LAKEVILLE MN 55044 6595 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 577 031142077006 KEVIN L HENRIKSEN 6600 LOWER 169TH ST W FARMINGTON MN 55024 -8037 6600 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 578 031142077004 MARILYN MECHAVICH 6605 W LOWER 169TH ST FARMINGTON MN 55024 6605 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 579 031142077004 ALLEN F & KAREN M MOLLER 6615 LOWER 169TH ST W FARMINGTONMN 55024 -9108 6615 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 580 031142077004 JUSTIN L BEAR 6635 LOWER 169TH ST W FARMINGTONMN 55024 -9108 6635 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 581 031142077004 PHILIP & REBECCA PALMER 6645 LOWER 169TH ST W FARMINGTONMN 55024 -9108 6645 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 94,471.51 582 031142077006 MARGARET H BUNKHOLT 6650 LOWER 169TH ST W FARMINGTONMN 55024 -9107 6650 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 583 031142077004 JAMES J & CATHERINE BREITER 6665 LOWER 169TH ST W FARMINGTON MN 55024 -9108 6665 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 584 031142077004 GARY D & DEBORAH S KAL STAB 6675 LOWER 169TH ST W FARMINGTONMN 55024 -9108 6675 LOWER 169TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 585 031142077004 JERRY JR PROFANT 6695 LOWER 169TH ST W FARMINGTONMN 55024 6695 LOWER 169TH ST W RESIDENTIAL 1 $4.471.51 $4,471.51 586 031142077003 DAVID L STRICKLAND 16840 FLORIN AVE FARMINGTONMN 55024 -8034 16840 FLORIN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 587 031142077003 THOMAS M & JUDITH A JOYCE 16860 FLORIN AVE FARMINGTON MN 55024 -8034 16860 FLORIN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 588 031142077004 PHILLIP KAUFMAN 16875 FLORIN AVE FARMINGTON MN 55024 -9499 16875 FLORIN AVE RESIDENTIAL 1 $4,47171 $4,471.51 589 031142077003 ROBE I & PATRICIA A LEE 16880 FLORIN AVE FARMINGTON MN 55024 -8034 16880 FLORIN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 590 031142077004 JOHN B & KIMBERLY M MB.BERT 16895 FLORIN AVE W FARMINGTON MN 55024 -9499 16895 FLORIN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 591 031142077003 MSP PROPERTIES LLC 6101 TINGDALE AVE EDINA MN 55436 16900 FLORIN AVE RESIDENTIAL 1 54,471.51 $4,471.51 592 031142077004 MERRB.EE FISHER 16905 FLORIN AVE FARMINGTON MN 55024 -9499 16905 FLORIN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 593 031142077003 ROBERTJSANDE 16920 FLORIN AVE FARMINGTON MN 55024 16920 FLORIN AVE RESIDENTIAL 1 $4,47171 54,471.51 594 031142077005 TERRY A& SHELLYM KOCH 16925 FLORIN AVE FARMINGTON MN 55024 -9499 16925 FLORIN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 595 031142077003 JACOB S BOERBOON 16940 FLORIN AVE. FARMINGTONMN 55024 -9497 16940 FLORIN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 596 031142077005 THOMAS A & MARGARET SVIEN 16945 FLORIN AVE. FARMINGTONMN 55024 -9499 16945 FLORIN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 597 031142077002 RICHARD STOCK 16960 FLORIN AVE FARMINGTONMN 55024 -9497 16960 FLORIN AVE RESIDENTIAL 1 $4,471.51 94,471.51 598 031142077005 LINDAEDOWELL 16965 FLORIN AVE FARMINGTON MN 55024 -9499 16965 FLORIN AVE RESIDENTAL 1 $4,471.51 $4,471.51 599 1 031142077002 LINDA CARLSON 16980 FLORIN AVE FARMINGTONMN 55024 -9497 16980 FLORIN AVE RESIDENTIAL 1 $4471.51 $4,471.51 600 031142077002 ARTHUR SEIFERT 16990 FLORIN AVE FARMINGTON MN 55024 -9497 16990 FLORIN AVE RESIDENTIAL 1 $4,471.51 $4,471.51 601 031142077006 WILLIAM R &BONITA KNETSCH 6622 FLOUNDER AVE FARMINGTON MN 55024 -9101 6622 FLOUNDERAVE RESIDENTIAL 1 $4,471.51 $4,471.51 602 031142077006 THOMAS DUANE PETERSEN 6610FLOUNDERCT FARMINGTONMN 55024 -9101 6610 FL OUNDER CT RESIDENTIAL 1 $4,471.51 $4,471.51 603 031142077006 ANNETTE E DAWSON 6614 FLOUNDER AVE FARMINGTON MN 55024 -9101 6614FLOUNDERCT RESIDENTIAL 1 54,471.51 $4,471.51 604 031142077006 DENNIS K& MARY J GUSTAFSON 6618 FLOUNDER AVE FARMINGTON MN 55024 -9101 6618 FLOUNDER CT RESIDENTIAL I 94,471.51 $4,471.51 605 031142077006 PETER &CAROLYN HUNTER 6626 FLOUNDER CT FARMINGTON MN 55024 6626 FLOUNDER CT RESIDENTIAL 1 $4,471.51 $4,471.51 606 031142077006 MATFHEWRRAHN 6630 FLOUNDER CT FARMINGTONMN 55024 6630 FLOUNDER CT RESIDENTIAL 1 $4,471.51 $4,471.51 607 031142055002 C JACOB & KATHRYN CHANDY 16890 GARCIA WAY ROSEMOUNT MN 55068 -5112 16890 GARCIA WAY RESIDENTIAL 1 $1,924.26 $1,924.26 608 031142055001 CRAIG N & MARI L OL SON 16899 GARCIA WAY W ROSEMOUNT MN 55068 16899 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 609 031142055002 MICHAEL CARL LB.IENKAMP 1 4548 141ST ST W I APPLE VALLEY MN 55124 16900 GARCIA WAY RESIDENTIAL 1 $1,924.26 $1,924.26 610 031142055001 GUANO LIEN FAN 16905 GARCIA WAY W ROSEMOUNT MN 55068 16905 GARCW WAY RESIDENTIAL 1 $4,471.51 $4,471.51 611 031142055003 ANDREW W &LINDAKMCCBESNEY 16906 GARCIA WAY ROSEMOUNT MN 55068 -5112 16906 GARCIA WAY RESIDENTIAL 1 54,471.51 $4,471.51 612 031142055001 CARL O &ELLEN FOASBERG 16909 GARCIA WAY ROSEMOUNT MN SS068 -5119 16909 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 613 031142055003 CLARK D &MARILYN S OLSON 16910 GARCIA WAY ROSEMOUNT MN 55068 -5112 16910 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 614 031142055001 GREGORY & DEBORAH BOEMER 16913: GARCIA WAY I ROSEMOUNT MN I 55068 -5145 1 16913 GARCIA WAY RESIDENTIAL 1 1 $4,471.51 I $4,471.51 615 031142055003 GREGORY J & BRIDGET KOTEK 16914 GARCIA WAY ROSEMOUNT MN 55068 -5112 16914 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 616 031142055001 JOHN I& CAROLYN A BECKER 16917 GARCIA WAY ROSEMOUNT MN 55068 -5145 16917 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 Preliminary Assessment Roll WSB P-Jecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Addition Restdmtial Pm Uuit AssessmmtRate: 92,166.96 Reviaed. 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Fernando WU, Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161sts& -4161. S&-4 162.d Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSB Pr jectNo, 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 617 031142055003 VENKATASUBRAMANI SRINIVASAN 16918 GARCIA WAY W ROSEMOUNT MN 55068 16918 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 618 031142055001 ARDEN A & SHARON K APITZ 16923 GARCIA WAY ROSEMOUNT MN 55068 -5145 16923 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 619 031142055003 ERIKAKRUSTANS 16924 GARCIA WAY ROSEMOUNT MN 55068 -5112 16924 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 620 031142055001 DONALD &DAWN ERICKSON 16929 GARCIA WAY ROSEMOUNT MN 55068 -5145 16929 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 621 031142055003 WAYNE C & KAREN A GANZHORN 16930 GARCIA WAY ROSEMOUNT MN 55068 -5112 16930 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 622 031142055001 KATHY LYNN COOK 16935 GARCIA WAY ROSEMOUNTMN 55068 -5145 16935 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 623 031142055003 ALLEN & MARGUERITA SCOTT 16936 GARCIA WAY W ROSEMOUNT MN 55068 16936 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 624 031142055002 JOHN GAGE 16941 GARCIA WAY NW ROSEMOUNT MN 55068 16941 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 625 031142055003 JAMES A& CATHERINE ROEMHILDT 15050 CEDAR AVE S BE 16 -316 APPLE VALLEY MN 55124 16942 GARCIA WAY RESIDENTIAL 2 $4,471.51 $8,943.02 626 031142055002 CHARLES O TSTE JACOBSON 4908 CLINTON AVE S MINNEAPOLIS MN 55409 -2661 16947 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 627 031142055002 MARFAM PROPERTIES LLC 13305 OLIVIA AVES BURNSVILLE MN 55337 16953 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 628 031142055002 BRIAN& MARTINA EDGREN 14189 GARLAND AVE APPLE VALLEY MN 55124 16955 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 629 031142055002 DANIEL P& CONNIE J BOERNER 601IRNAMWOODDR BURNSVILLE MN 55337 16959 GARCIA WAY RESIDENTIAL 1 $4.471.51 $4,471.51 630 031142055003 JOHN E GAGE 19279 ENCORE CT FARMINGTON MN 55024 16960 GARCIA WAY RESIDENTIAL 1 $4,471.51 $4,471.51 631 101142033000 CHAD S &NICOLE HARTJE 7442170THCTW ROSEMOUNTMN 55068 -5105 7442170TH CT RESIDENTIAL 1 $4,4717 $4,471.51 632 101142033001 BRIAN L & KIMBERLY J RAMAKER 7303 170TH STREET WEST ROSEMOUNT MN 55068 7303 170TH ST RESIDENTIAL 1 $1,924.26 $1,924.26 633 031142055003 SHENG I ME PO BOX 241602 APPLE VALLEY MN 55124 -1602 7429 170TH ST RESIDENTIAL 1 $4,471.51 34,471.51 634 101142033004 PATRICK J GANSMOE 7256 170TH ST W ROSEMOUNT MN 55068 -5150 7256 170TH ST W RESIDENTIAL 1 $1,924.26 51,924.26 635 101142033004 DAVID P & PATRICIA A BEGONI 7270 170TH ST W ROSEMOUNT MN 55068 -5150 7270 170TH ST W RESIDENTIAL 1 $1,924.26 S 1,924.26 636 101142033001 JEAN LOUISE PHIPPS 7287170TH ST ROSEMOUNT MN 55068 -5152 7287170TH ST RESIDENTIAL 1 $1,924.26 $1,924.26 637 101142033001 JIM R & TAMMY L POLAK 7319170TH ST ROSEMOUNTMN 55068 7319170TH STW RESIDENTIAL 1 $1,92426 $1,924.26 638 101142033001 MARK A& JULIAJSWANSON 7350170TESTW ROSEMOUNT MN 55068 7350170TH ST RESIDENTIAL 1 $1,924.26 $1,924.26 639 101142033001 ANDREW RBRUEMMER 7364170TH ST W ROSEMOUNTMN 55068 -5154 7364170TH ST W RESIDENTIAL 1 $1,924.26 51,924.26 640 031142055004 SHANNON E & ERIC R WEISS 7367 170TH ST W ROSEMOUNT MN 55068 7367 170TH ST W RESIDENTIAL 1 $1,924.26 S 1,924.26 641 031142055004 CHRISTOPHER BLACKBURN 7383 170TH ST W ROSEMOUNTMN 55068 7383 170TH ST W RESIDENTIAL 1 51,924.26 51,924.26 642 101142033001 JAMES R &GAIL AKOHLMANN 7390170TH ST ROSEMOUNTMN 55068 7390170TH ST RESIDENTIAL 1 $1,924.26 $1,924.26 643 031142055004 1 DAMWATIE ROOPAN SINGH 7399170TH ST ROSEMOUNT MN 55068 7399170TH ST RESIDENTIAL 1 $1,924.26 $1,924.26 644 031142055004 TERRY R CUSHMAN 26783 HIGHWAY 61 DAKOTA MN 55925 7465 170TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 645 101142033000 BRUCE WILCOX 7430 170TH CT W ROSEMOUNT MN 55068 -5105 7430 170TH STREET CT W RESIDENTIAL 1 $4,471.51 $4,471.51 646 101142033000 DARREL J EGERTSON 7434 170TH CT W ROSEMOUNT MN 55068 -5105 7434 170TH STREET CT W RESIDENTIAL 1 $4.471.51 $4,471.51 647 101142033000 PHILIP M & DANELLE M WELLS 7438 170TH CT W ROSEMOUNT MN 55068 -5104 7438 170TH STREET CT W RESIDENTIAL I 54,471.51 $4,471.51 648 101142033000 WM & JAC UELYN MITCHELL 7446 170TH CT W ROSEMOUNT MN 55068 -5104 7446 170TH STREET CT W RESIDENTIAL 1 94,471.51 $4,471.51 649 101142033006 FORREST G HERBST 7452 170TH CT W ROSEMOUNT MN 55068 -5105 7452 170TH STREET CT W RESIDENTIAL 1 $4,471.51 $4,471.51 650 101142033003 CHRISTOPHER E &JULI SCHUETZ 17050 GEORGETOWN CT ROSEMOUNT MN 55068 17050 GEORGETOWN CT RESIDENTIAL 1 51,92426 $1,924.26 651 101142033003 CHARLES M & BRIANA B LITTLE 17053 GEORGETOWN CT ROSEMOUNTMN 55068 -5161 17053 GEORGETOWN CT RESIDENTIAL 1 $1,924.26 $1,924.26 652 101142033003 KAY L ULICK 17058 GEORGETOWN CT ROSEMOUNT MN 55068 -5161 17058 GEORGETOWN CT RESIDENTIAL 1 $1,924.26 $1,92416 653 101142033003 DAVID &CARLA FRIEDT 17063 GEORGETOWN CT ROSEMOUNT MN I 55068 -5161 1 17063 GEORGETOWN CT RESIDENTIAL 1 $1,924.26 $1,924.26 654 101142033003 SCOTT &MARY JANE CARLSON 17066 GEORGETOWN CT ROSEMOUNT MN 1 55068 1 17066 GEORGETOWN CT RESIDENTIAL 1 $1,924.26 $1,924.26 655 101142033003 DANNYD& KAREN D BLENDERS 17071 GEORGETOWN CT ROSEMOUNT MN SS068 -5161 17071 GEORGETOWN CT RESIDENTIAL 1 $1,924.26 $1,924.26 656 101142033003 MARLINE MARY BURNS 17074 GEORGETOWN CT ROSEMOUNT MN SS068 -5161 17074 GEORGETOWN CT RESIDENTIAL 1 $1,924.26 $1,924.26 657 031142055004 KIM EVRAETS 16982 GEORGETOWN WAY ROSEMOUNT MN SS068 16982 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 658 031142055004 DANIEL F &KARENA MOERKE 16983 GEORGETOWN WAY ROSEMOUNT MN 55068 -5158 16983 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 659 031142055004 SANDESHKPREMDAS 16987 GEORGETOWN WAY ROSEMOUNT MN 55068 -5158 16987 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 I $1,924.26 660 031142055004 DANIEL 0 MASON 16988 GEORGETOWN WAY I ROSEMOUNT MN I 55068 -5155 1 16988 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 1 $1,924.26 Preliminary Assessment Roll WSB P-Jec& 20145 &eetRe construction Project R —txoct Proposed Reidmdal Pet Uuit Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Adding, RAdmttal Pm Uuit Ass ®smmtRate: 52,166.96 Reviaed. 1012112013 Cedar IBghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Fai,Ween Avenue, Fantasia Avenge, Farcry Way, Fernand, Avenue, Fernando Wary Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FkgslaffWav, Fo"ge Avenge, Lower 161sts&ee4 161. S&-4 162.d S&ee6163rd Street, 164& S&eet, Lower 169th Stree 4 169th S &eef, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 Gearge[awn Way, I70th S&-4 I70th Court WSB Pr jectNo, 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF FES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 661 031142055004 RONALDJ &LORIAGEIWDZ 16991 GEORGETOWN WAY ROSEMOUNTMN 55068 16991 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 662 101142033006 ROBERT J &ALYSSA DODDS 16992 GEORGETOWN WAY ROSEMOUNT MN 55068 -5155 16992 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 663 101142033004 MICHAEL J HOFFMAN 17004 GEORGETOWN WAY ROSEMOUNT MN 55068 17004 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 664 101142033004 KENTTJOYNER 17008 GEORGETOWN WAY ROSEMOUNT MN 55068 -5160 17008 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 665 101142033901 MICHAEL D& KELL Y L ROBINS ON 17009 GEORGETOWN WAY ROSEMOUNT MN 55068 -5159 17009 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 666 101142033904 KEVIN &MARY ANN FOX 17012 GEORGETOWN WAY ROSEMOUNTMN 55068 -5160 17012 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 667 101142033001 SHANE VINJE 17013 GEORGETOWN WAY ROSEMOUNT MN 55068 17013 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 51,924.26 668 101142033004 BLAKE K& KATHERINE BENEDICT 17016 GEORGE TOWN WAY ROSEMOUNT MN 55068 - 5160 17016. GEORGETOWN WAY RESIDENTIAL 1 51,924.26 51,924.26 669 101142033001 ACID KILIAKI 17017 GEORGETOWN WAY ROSEMOUNTMN 55068 17017 GEORGETOWN WAY RESIDENTIAL 1 51,924.26 51,924.26 670 101142033004 DESMONDRNURSE 17022 GEORGETOWN WAY ROSEMOUNTMN 55068 -5160 17022 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 51.924.26 671 101142033001 NOUHAR& KAMALDAI JAWAIRAM 17023 GEORGETOWN WAY ROSEMOUNT MN 55068 -5159 17023 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 51,924.26 672 101142033004 CASSIE J GROFF 17026 GEORGETOWN WAY ROSEMOUNT MN 55068 -5160 17026 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 51,924.26 673 101142033002 CHANDRA &JENNIFER SHIVCHARRAN 17027 GEORGETOWN WAY ROSEMOUNT MN 55068 -5159 17027 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 674 101142033002 ROBERT M & CAROL IPB.CHER 17031 GEORGETOWN WAY ROSEMOUNT MN 55068 -5159 17031 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 675 101142033004 MARK A & DEANNA L MILLER 17032 GEORGETOWN WAY ROSEMOUNT MN 55068 -5160 17032 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 676 101142033002 STEVE & REBECCA BERGE 17037GEORGETOWNWAY ROSEMOUNT MN 55068 -5159 17037 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 677 101142033002 FEDERAL HOME LOAN MORTGAGE CORPORATION 5000 PLANO PKWY CARROLLTON TX 1 75010 -4900 17041 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 678 101142033002 ROBERTANAYLOR 17045 GEORGETOWN WAY ROSEMOUNT MN 55068 17045 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 51,924.26 679 101142033002 REYNOLD G &SANDRA JADOO 17051 GEORGETOWN WAY ROSEMOUNT MN 55068 -5159 17051 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 51,924.26 680 101142033005 NGOC LAM TUNG NGUYEN 17052 GEORGETOWN WAY ROSEMOUNT MN 55068 17052 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 681 101142033902 NANCY C KOCER 17055 GEORGETOWN WAY ROSEMOUNTMN 55068 -5159 17055 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 682 101142033902 ANGELA J &DANNY D SWENSON 17061 GEORGETOWN WAY ROSEMOUNT MN 55068 17061 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 683 101142033005 MILDRED E OBRIEN 17064 GEORGETOWN WAY ROSEMOUNT MN 55068 -5160 17064 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 51,924.26 684 101142033002 MICHAEL L B PURDY 17065 GEORGETOWN WAY ROSEMOUNT MN 55068 - 5159 17065 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 51,924.26 685 101142033005 STEVEN LOTZER 17068 GEORGETOWN WAY ROSEMOUNT MN 55068 -5160 17068 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 51,924.26 686 101142033002 BRIAN ITOLLEFSON 153 PINEBROOK DR W BRANDON MS 39047 17069 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 687 1 101142033003 ALVIN WILBERT SMITH 17075 GEORGETOWN WAY ROSEMOUNT MN 55068 -5159 17075 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 688 101142033005 ERIC K COWAN 17076 GEORGETOWN WAY ROSEMOUNT MN 55068 -5160 17076 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 689 101142033003 BRIANRHART 17079 GEORGETOWN WAY ROSEMOUNT MN 55068 -5159 17079 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 690 101142033005 MICHAEL L LAWRENCE 17082 GEORGETOWN WAY ROSEMOUNT MN 55068 -5160 17082 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 691 101142033003 TIMOTHY I& CAROL M MESZAROS 17083 GEORGETOWN WAY ROSEMOUNT MN 55068 -5159 17083 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 692 101142033005 VICKIYLANGSDORF 17086 GEORGETOWN WAY ROSEMOUNTMN 55068 -5160 17086 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 693 101142033005 QUANTNGUYEN 17090 GEORGETOWN WAY ROSEMOUNTMN 55068 -5160 17090 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 694 101142033005 TROY VISNOVEC 17094 GEORGETOWN WAY ROSEMOUNT MN 55068 17094 GEORGETOWN WAY RESIDENTIAL 1 $1,92426 $1,924.26 695 101142033004 ALYSSA THEY NGUYEN 17097 GEORGETOWN WAY ROSEMOUNT MN 55068 -5159 17097 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 696 101142033005 RICHELLEC WITHA 17098 GEORGETOWN WAY ROSEMOUNT MN 55068 -5160 17098 GEORGETOWN WAY RESIDENTIAL 1 $1,924.26 $1,924.26 697 031142015001 INDEPENDENT SCHOOL DIST 196 3455 153RD ST W ROSEMOUNT MN 1 55068 -4946 6795 GERDINE PATH RESIDENTIAL 6 $4,471.51 $26,829.06 698 021142033900 ANITA & NIGEL ESS 6456 160TH ST ROSEMOUNT MN 55068 6456 160TH ST W RESIDENTIAL 1 $4,471.51 $4,471.51 699 101142031005 CITY OF LAKEVILLE 20195 HOLYOKE AVE LAKEVILLE MN 55044 -9047 1 E $7,697.05 700 101142033000 CITY OF LAKEVILLE 20195 HOLYOKE AVE LAKEVILLE MN 55044 -9047 5 $1,924. $9,621.31 701 021142037000 CITY OF LAKEVILLE 20195 HOLYOKE AVE EMILLE MN 55044 -9047 5 $4,471.51 $22,357.55 702 031142011010 MIKEL &BARBARADRECZKO 16113 FLAGSTAFF CTN ROSEMOUNT MN 55068 -1255 16113 FLAGSTAFF CT N RESIDENTIAL 0.5 $2,166.96 $1,083.48 703 031142011010 GRAFFUNDERLLC 9932 MAPLE AVES BLOOMINGTONMN 55431 16111 FLAGSTAFF CTN RESIDENTIAL 0.5 $2,166.96 $1,083.48 704 031142011011 COLIN GOODSON 16109 FLAGSTAFF CT N ROSEMOUNT MN 55068 16109 FLAGSTAFF CTN RESIDENTIAL 0.5 $2,166.96 1 $1,083.48 Preliminary Assessment Roll WSB P-Jecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi- City ofLakeville Niakma Vifiage2od Addition Restdmtial Pm Uuit AssessmmtRate: 92,166.96 Reviaed: 1012112013 Cedar IBghlaods 5th Addifian Resideofial Per Unit Assessmmt Rate: $1,924.26 Dodd Lane, Fxcel Way, E-L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Femando Wary Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161sts&- 4161st Shee6162nd Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSBPr jctNo.: 02109 -391 API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION SF RES. EQUIV. UNITS SF UNIT ASSESSMENT RATE PROPOSED ASSESSMENT 705 031142011011 TAFLA J JOHNSON 16115 FLAGSTAFF CTN ROSEMOUNT MN 55068 16115 FLAGSTAFF CT N RESIDENTIAL 0.5 $2,166.96 $1,083.48 706 031142011011 LEE RANDALL KRATZER 16117 FLAGSTAFF CT N ROSEMOUNT MN 55068 16117 FLAGSTAFF CT N RESIDENTIAL 0.5 $2,166.96 $1,083.48 707 031142011011 MOLLY WELLER 16119 FLAGSTAFF CT N ROSEMOUNT MN 55068 16119 FLAGSTAFF CT N RESIDENTIAL 0.5 $2,166.96 $1,083.48 708 031142011011 BRADLEY A REBECCA M LANGE 16121 FLAGSTAFF CT N ROSEMOUNT MN 55068 -1255 16121 FLAGSTAFF CT N RESIDENTIAL 0.5 $2,166.96 $1,083.48 709 031142011011 AMI JGROTE 16123 FLAGSTAFF CTN ROSEMOUNT MN 55068 -1255 16123 FLAGSTAFF CTN RESIDENTIAL 0.5 $2,166.96 $1,083.48 710 031142011011 ANITA J TAYSON 16125 FLAGSTAFF CTN ROSEMOUNT MN 55068 -1275 16125 FLAGSTAFF CT N RESIDENTIAL 0.5 $2,166.96 $1,083.48 711 031142011011 CARLENE WOLF 16127 FLAGSTAFF CT N ROSEMOUNT MN 55068 -1275 16127 FLAGSTAFF CT N RESIDENTIAL 0.5 52,166.96 51,083.48 712 031142011011 KENNETH& DEBRA J MERIGOLD 16129 FLAGSTAFF CT N ROSEMOUNT MN 55068 -1275 16129 FLAGSTAFF CTN RESIDENTIAL 0.5 $2,166.96 51,083.48 713 031142011011 WESS STROMGREN 16131 FLAGSTAFF CTN ROSEMOUNT MN 55068 16131 FLAGSTAFF CT N RESIDENTIAL 0.5 52,166.96 51,08748 714 031142011012 HARRY E& MARCELLA JARCHOW 16133 FLAGSTAFF CTN ROSEMOUNT MN 55068 -1275 16133 FLAGSTAFF CTN RESIDENTIAL 0.5 $2,166.96 $1,083.48 715 031142011012 LAURA A MCCLELLAN 16135 FLAGSTAFF CT N ROSEMOUNT MN 55068 16135 FLAGSTAFF CT N RESIDENTIAL 0.5 $2,166.96 $1,083.48 716 031142011012 ADAM OLAF DAGSGARD 16137 FLAGSTAFF CT N ROSEMOUNTMN 55068 -1275 16137 FLAGSTAFF CTN RESIDENTIAL 0.5 $2,166.96 $1,083.48 717 031142011012 CHRISTOPHER REICHERTS 16139 FLAGSTAFF CTN ROSEMOUNTMN 55068 -1275 16139 FLAGSTAFF CTN RESIDENTIAL 0.5 $2,166.96 $1,083.48 718 031142011012 JOSEPHMKESSLER 16141 FLAGSTAFF CTN ROSEMOUNT MN 55068 16141 FLAGSTAFF CT N RESIDENTIAL 0.5 $2,166.96 $1,083.48 719 031142011012 CORRINE L TSTE BERKMAN 16143 FLAGSTAFF CT N ROSEMOUNT MN 55068 -1212 16143 FLAGSTAFF CT N RESIDENTIAL 0.5 $2,166.96 $1,083.48 720 031142011012 ADAM )VOLD 16145 FLAGSTAFF CT N ROSEMOUNT MN 55068 -1212 16145 FLAGSTAFF CTN RESIDENTIAL 0.5 $2,166.96 $1,083.48 721 031142011012 BRIAN G MEHLHOP 16671 FALKIRK TRL LAKEVILLE MN 55044 16147 FLAGSTAFF CT N RESIDENTIAL 0.5 $2,166.96 $1,083.48 722 031142011012 CHARLES E DODGEN 16149 FLAGSTAFF CT N ROSEMOUNT MN 55068 -1212 16149 FLAGSTAFF CT N RESIDENTIAL 0.5 $2,166.96 $1,083.48 723 031142011012 TRISHAM WEISS 16151 FLAGSTAFF CT N ROSEMOUNT MN 55068 -1212 16151 FLAGSTAFF CT N RESIDENTIAL 0.5 $2,166.96 $1,083.48 724 031142011013 CURTIS EUGENE VANCURA 16153 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1258 16153 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 725 031142011013 DOROTHYHOLSTAD PO BOX 622 LAKEVILLE MN 55044 16155 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 726 031142011013 CHANTEL SZAMBELAN 16157 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1258 16157 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 727 031142011013 TYLER BEAUCHAMP 16159 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1258 16159 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 728 031142011013 ALAN F & SHARON M RYBAK 12260 175TH ST W LAKEVILLE MN 55044 16161 FLAGSTAFF CT S RESIDENTIAL 0.5 52,166.96 $1,083.48 729 031142011013 BRANDON HINRICHS 16163 FLAGSTAFF CT S ROSEMOUNT MN 55068 16163 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 730 031142011013 DENNIS D BALLESTEROS 570 CAYLIN CT EAGAN MN 55123 16165 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 731 031142011013 LEXANDRA A SISKO 16167 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1258 16167 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 732 031142011013 GEORGE O MONGARE 16169 FLAGGSTAFF CT S ROSEMOUNT MN 55068 -1277 16169 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 733 031142011013 ARTHUR J HANCOCK 16171 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1277 16171 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 734 031142011014 CHAD & JENNIFER VELDE 16173 FLAGSTAFF CT S ROSEMOUNTMN 55068 -1277 16173 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 735 031142011014 JASON & SHELLY WOLFE 19604 CALUMET CT FARMINGTON MN 55024 16175 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 736 031142011014 DONALD B& MAY ANN WILLIAMS 16177 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1277 16177 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 737 031142011014 DEBORAH JLENTSCH 16179 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1277 16179 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 738 031142011014 STEVEN D &JEANM OLSON 16181 FLAGSTAFF CT S ROSEMOUNT MN 55068 16181 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 739 031142011014 DIANE C COX 16183 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1277 16183 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 740 031142011014 DEBORAH KNELSON 16185 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1263 16185 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 741 031142011014 ILIYA B BERDICHEVSKI 10968 ALISON CT RGROVE HEIGHTS 55077 16187 FLAGSTAFF CT S RESIDENTIAL 0.5 $2166.96 $1,083.48 742 031142011014 BRENT REICHOW 16189 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1263 16189 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 743 031142011014 LORI ALINDEMANN 16191 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1263 16191 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 51,083.48 744 031142011015 MARK L & SHIRLEY A SU UIST 7029 LAMOTTE.DR CENTERVILLE MN 55038 16193 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 51,083.48 745 031142011015 JILL A BERGLAND 16195 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1263 16195 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 746 031142011015 LEE E & LOWELL B RUSSELL 16197 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1263 16197 FLAGSTAFF CT S RESIDENTIAL 0.5 1 $2,166.96 1 $1,083.48 747 031142011015 ALAN &SHARON RYBAK 12260175TH STW LAKEVILLEMN 55044 16199 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 748 031142011015 JAMES JR RICE 16201 FLAGSTAFF CT S ROSEMOUNT MN 55068 16101 FLAGSTAFF CT S RESIDENTIAL 0.5 1 $2,166.96 1 $1,083.48 Preliminary Assessment Roll WSB Proiecti 2014 Sheet Re construction Project Retoostratt Proposed Re idmtiul Pet Untt Assessm mt Rate: $4,471.51 Date: 81812013 PraieceLo fi— City ofLakeville Niakma Vifiage2od Addition Restdmtial Pm Uuit AssessmmtRate: 92,166.96 Reviaed. 1012112013 Cedar IDghlaods 5th Addifian R.ideofial Per Unit A.—.mt Rate: $1,924.26 Dodd Lane, Fxcel Way, E—L,im Drive, Excelsior Cogr6 Foi,Ween Avenue, Fantasia Avenge, Farcry Way, Fernando Avenue, Fernando WU, Finch Avenge, Finch Way, Findland Avenue, Findlay Way, Finesse Way, Fishing Avenue, Fishing Way, FZagsfaffAvenaze, FlagstaffCoazrtNartk, FlagslaffCoazrt South, FLrgslaffWav, Fo"ge Avenge, Lower 161sts& -4161. Shee6162nd Sb e6163rd Sheet, 164& Sheet, Lower 169th Stree 4 169th Street, Florin Avenue, Flounder CoazrS Garcia Way, Georgetown Cour4 George[own Way, I70th Street, I70th Court WSBPr jectNo, 02109 -391 SF FES. SF UNIT API PID FEE OWNER FEE OWNER ADDRESS CITY/STATE ZIP CODE PROPERTY ADDRESS USEDESCRIPTION EQUIV. ASSESSMENT PROPOSED UNITS RATE ASSESSMENT 749 031142011015 DENISE L CIOLA 16203 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1269 16203 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 750 031142011015 JUSTIN C KLEIN 16205 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1269 16205 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 751 031142011015 SHEILA ILINDELL 16207 FLAGSTAFF CT S ROSEMOUNT MN 55068 16207 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 752 031142011015 BOBBIEDMORGAN 16209 FLAGSTAFF CT S ROSEMOUNT MN 55068 16209 FLAGSTAFF CT S RESIDENTIAL 0.5 $2,166.96 $1,083.48 753 031142011015 MARGO L MEYER 16211 FLAGSTAFF CT S ROSEMOUNT MN 55068 -1271 16211 FLAGSTAFF CT S RESIDENTIAL 0.5 52.166.96 51.083.48 TOTAL ASSESSMENTS $3,055,353.01 APPENDIX D 2013 Geotechnical Report — Log of Test Borings Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 BRAUN INTERTEC o o� F >�oz ¢www Ovrc O� a c� Onw LL B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: STA GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/11/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 4 inches of bituminous over 10 inches of aggregate base. — 1.2 FILL FILL: Clayey Sand, dark brown, moist. 3.0 7 FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, brown, moist. 7 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -1 page 1 of 1 BRAUN"' I NTE RTEC LOG OF BORING Braun Project BL -13 -05734 BORING: ST -2 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/11/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 2 1/2 inches of bituminous over 3 1/2 inches of aggregate base. 1.0 FILL FILL: Silty Sand, fine- to medium - grained, with Clayey Sand layer, brown, moist. 2 FILL SP- FILL: Clayey Sand, brown, moist. POORLY GRADED SAND with SILT, fine- to medium- grained, SM 15 trace Gravel, brown, moist, medium dense. — (Glacial Outwash) 21 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -2 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -3 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/11/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) 0.6 PAV 4 inches of bituminous over 3 1/2 inches of aggregate base. — FILL FILL: Silty Sand, fine- to medium- grained, dark brown, moist. 2.0 FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, — with Gravel, brown, moist. 11 4.0 FILL FILL: Sandy Lean Clay, brown, moist. 6 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -3 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -4 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/11/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) 0.8 PAV 2 1/2 inches of bituminous over 7 inches of aggregate base. FILL: Clayey Sand, fine- to medium- grained, dark brown, moist. — FILL 2.0 FILL FILL: Silty Sand, fine- to coarse - grained, trace Gravel and Clayey Sand, brown, moist. 18 4.0 SP- POORLY GRADED SAND with SILT, fine- to medium - grained, SM trace Gravel, brown, moist, medium dense. (Glacial Outwash) 25 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) . U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST-4 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -5 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/11/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 3 inches of bituminous over 10 inches of aggregate base. 1.1 FILL: Poorly Graded Sand with Silt, fine- to medium - grained, FILL — brown, moist. (Possible Fill) 11 7 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -5 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -6 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/11/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 3 inches of bituminous over 10 1/2 inches of aggregate base. — 1.2 FILL FILL: Silty Sand, fine- to medium - grained, with Gravel, brown, — moist. _ 15 4.0 SP- POORLY GRADED SAND with SILT, fine- to medium - grained, SM trace Gravel, brown, moist, medium dense. (Glacial Outwash) 11 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -6 page 1 of 1 B RAU NS°' NTE RTEC LOG OF BORING Braun Project BL -13 -05734 BORING: ST -7 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/11/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 3 inches of bituminous over 8 1/2 inches of aggregate base. 1.0 FILL: Silty Sand, fine- to medium - grained, dark brown, moist. FILL 2.0 SP- POORLY GRADED SAND with SILT, fine- to medium - grained, SM brown, moist, loose to medium dense. 14 6 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -7 page 1 of 1 BRAUN"' I NTE RTEC LOG OF BORING Braun Project BL -13 -05734 BORING: ST -8 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/11/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 2 1/4 inches of bituminous. — FILL FILL: Silty Sand, fine- to medium - grained, dark brown, moist. 2.0 FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, 3.0 brown, moist. 14 SP- POORLY GRADED SAND with SILT, fine- to medium- grained, — SM brown, moist, medium dense. (Glacial Outwash) 17 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -8 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -9 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/11/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) 0.7 PAV 2 1 /2inches of bituminous over 5 1/2 inches of aggregate base. — FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, trace Gravel, Clay layers, brown, moist. _ 13 4.0 SP- POORLY GRADED SAND with SILT, fine- to medium - grained, SM brown, moist, medium dense. (Glacial Outwash) 16 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) . U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -9 page 1 of 1 BRAUN"' I NTE RTEC LOG OF BORING Braun Project BL -13 -05734 BORING: ST -10 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/11/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 2 1/2 inches of bituminous. — FILL FILL: Silty Sand, fine- to medium - grained, with Gravel, dark brown, moist. 2.5 12 — SP- POORLY GRADED SAND with SILT, fine- to medium- grained, SM brown to light brown, moist, medium dense. — (Glacial Outwash) A 23 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -10 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -11 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/11/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV hes of bituminous over 15 1/2 inches of aggregate 1.5 7se. 2.0 FILL layey Sand, brown, moist. SP- Y GRADED SAND with SILT, fine- to medium - grained, — SM brown, moist, medium dense. 18 (Glacial Outwash) 22 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -11 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -12 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/12/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 3 1/2 inches of bituminous over 17 1/2 inches of aggregate base. 1.8 — CL LEAN CLAY with SAND, brown, moist, rather soft to rather stiff. (Glacial Till) 4 4 10 Gray at 10 feet. 12 11.0 END OF BORING. Water not observed to cave -in depth of 8 1/2 fe — tiedia after withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 Q) Q) S BL -13 -05734 Braun Intertec Corporation ST -12 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -13 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/12/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 5 1/2 inches of bituminous over 10 inches of aggregate base. — 1.3 CL LEAN CLAY with SAND, brown, moist, rather stiff to very stiff. — (Glacial Till) 9 Brown and gray at 5 feet. 11 Gray at 7 1/2 feet. 24 13 11.0 END OF BORING. Water not observed to cave -in depth of 8 feet i me lately er — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 Q) Q) S BL -13 -05734 Braun Intertec Corporation ST -13 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -14 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/12/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 4 inches of bituminous over 10 inches of aggregate base. — 1.2 SP- POORLY GRADED SAND with SILT, fine- to coarse - grained, — SM Clayey inclusions, brown, wet, rather stiff. (Glacial Till) 7 4.0 An open triangle in the water SC CLAYEY SAND, brown, waterbearing, soft to medium dense. (Glacial Till) level (WL) column indicates 3 the depth at which — groundwater was observed while drilling. Groundwater — levels fluctuate. 8 7 11.0 END OF BORING. Water observed at a depth of 4 feet while drillin . Boring then backfilled. . U N N 0 Q) Q) S BL -13 -05734 Braun Intertec Corporation ST -14 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -15 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/12/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 3 inches of bituminous over 8 inches of aggregate base. 0.9 FILL: Poorly Graded Sand with Silt, fine- to medium- grained, FILL _ brown, wet to waterbearing. 2.5 8 _ CL LEAN CLAY with SAND, brown, moist to wet, rather stiff to stiff. (Glacial Till) 7 14 13 11.0 END OF BORING. Water not observed to cave -in depth of 8 feet i me lately er — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 Q) Q) S BL -13 -05734 Braun Intertec Corporation ST -15 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -16 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/12/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 4 1/2 inches of bituminous over 6 inches of aggregate base. 0.9 FILL: Poorly Graded Sand with Silt, fine- to medium- grained, FILL brown, moist. _ 8 4.0 CL LEAN CLAY with SAND, grayish brown, wet, rather soft to rather stiff. (Glacial Till) 4 8.0 g CL SANDY LEAN CLAY, brown, wet, medium. (Glacial Till) 8 11.0 END OF BORING. Water not observed to cave -in depth of 8 1/2 fe7im iately after withdrawal of auger. Boring then backfilled. Q) . U N N 0 Q) Q) S BL -13 -05734 Braun Intertec Corporation ST -16 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -17 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/12/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 3 inches of bituminous over 12 inches of aggregate base. — 1.3 FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, — with Gravel, brown, moist. (Possible Fill) 10 6 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -17 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -18 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/12/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PA V of bituminous over 21 inches of aggregate base. 2.0 7inhes FILL oorly Graded Sand with Silt, fine- to medium - grained, trace Gravel, dark brown, moist. 13 4.0 SP- POORLY GRADED SAND with SILT, fine- to medium - grained, SM trace Gravel, brown, moist, medium dense. (Glacial Outwash) 15 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled.Boring then backfilled. Q) . U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -18 page 1 of 1 B RAU NS°' NTE RTEC LOG OF BORING Braun Project BL -13 -05734 BORING: ST -19 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/12/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 4 inches of bituminous over 10 inches of aggregate base. — 1.2 SP- POORLY GRADED SAND with SILT, fine- to medium - grained, — SM trace Gravel, light brown, moist, dense. (Glacial Outwash) 36 33 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -19 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -20 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/12/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) 0 PAV 2 inches of bituminous over 6 1/2 inches of aggregate base. — FILL FILL: Silty Sand, fine- to medium - grained, with Gravel, brown, moist. 2.5 7 SP- POORLY GRADED SAND with SILT, fine- to medium - grained, SM brown, moist, loose to medium dense. — (Glacial Outwash) 12 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -20 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -21 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/12/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) 0.6 PAV 2 1/2 inches of bituminous over 4 1/2 inches of aggregate base. 1.5 FILL FILL: Silty Sand, fine- to medium - grained, brown, moist. FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, brown, moist. — (Possible Fill) 7 4 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -21 page 1 of 1 BRAUN"' I NTE RTEC LOG OF BORING Braun Project BL -13 -05734 BORING: ST -22 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/12/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 3 1/2 inches of bituminous over 2 1/2 inches of aggregate base. 1.5 FILL FILL: Silty Sand, fine- to medium - grained, brown, moist. — SP- POORLY GRADED SAND with SILT, fine- to medium - grained, SM trace Gravel, brown, moist, loose to medium dense. — (Glacial Outwash) 7 13 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -22 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -23 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) 0.6 PAV 3 inches of bituminous over 3 1/2 inches of aggregate base. — FILL FILL: Poorly Graded Sand with Silt, fine- to medium- grained, brown, moist. — 12 5.0 22 SP- POORLY GRADED SAND with SILT, fine- to medium - grained, 6.0 SM light brown, moist, medium dense. (Glacial Outwash) END OF BORING. — — Water not observed to cave -in depth of 4 1/2 feet immediately after withdrawal of auger. Boring then backfilled. Q) Q U Q) 0 Q) Q) S BL -13 -05734 Braun Intertec Corporation ST -23 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -24 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 3 inches of bituminous over 3 inches of aggregate base. 1.5 FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, trace Gravel, layers of Clayey Sand, dark brown, moist. 13 4.0 FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, trace Gravel, layers of Clayey Sand, dark brown and black, moist. 24 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) . U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -24 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -25 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) 0.6 PAV 3 1/2 inches of bituminous over 4 inches of aggregate base. — SP- POORLY GRADED SAND with SILT, fine- to medium - grained, SM brown, moist, medium dense. — (Glacial Outwash) — 29 18 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -25 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -26 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) 0 7 PAV 3 inches of bituminous over 5 inches of aggregate base. — SP- POORLY GRADED SAND with SILT, fine- to medium - grained, SM trace Gravel, light brown, moist, medium dense. — (Glacial Outwash) 25 18 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -26 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -27 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 2 1/2 inches of bituminous over 3 1/2 inches of aggregate base. — FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, with trace Silty Sand and Gravel, brown, moist. — 12 4.0 SP- POORLY GRADED SAND with SILT, fine- to medium - grained, SM brown, moist, loose. (Glacial Outwash) 10 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -27 page 1 of 1 BRAUN"' I NTE RTEC LOG OF BORING Braun Project BL -13 -05734 BORING: ST -28 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 3 inches of bituminous over 3 1/2 inches of aggregate base. — FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, trace Gravel, brown, moist. — 12 7 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -28 page 1 of 1 BRAUN"' I NTE RTEC LOG OF BORING Braun Project BL -13 -05734 BORING: ST -29 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 3 1/2 inches of bituminous over 2 1/2 inches of aggregate base. — FILL FILL: Silty Sand, fine- to medium - grained, dark brown, moist. 2.0 FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, — trace Gravel, and Clayey Sand, brown, moist. 13 (Possible Fill) 8 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) . U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -29 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -30 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) 0 8 PAV 3 inches of bituminous over 7 1/2 inches of aggregate base. POORLY GRADED SAND with SILT, fine- to medium- grained, — SP- SM trace Gravel, brown, moist, medium dense. (Glacial Outwash) _ 13 23 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -30 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -31 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) 0 8 PAV 3 inches of bituminous over 7 inches of aggregate base. FILL: Poorly Graded Sand with Silt, fine- to medium - grained, — FILL trace Gravel, brown, moist. (Possible Fill) 28 11 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -31 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -32 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 5 1/2 inches of bituminous over 6 1/2 inches of aggregate base. 1.0 FILL: Silty Sand, fine- to medium - grained, dark brown, moist. FILL 2.0 FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, brown, moist. (Possible Fill) 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) . U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -32 page 1 of 1 BRAUN"' I NTE RTEC LOG OF BORING Braun Project BL -13 -05734 BORING: ST -33 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 5 inches of bituminous. — FILL FILL: Silty Sand, fine- to medium - grained, trace Gravel, moist. 2.0 FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, — brown, moist. 15 (Possible Fill) 5 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -33 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -34 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 6 1/2 inches of bituminous over 5 1/2 inches of aggregate base. 1.0 FILL: Silty Sand, fine- to medium - grained, dark brown, moist. FILL 2.0 FILL FILL: Poorly Graded Sand with Silt, fine- to medium - grained, brown, moist. 16 (Possible Fill) 5 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -34 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -35 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 3 1/2 inches of bituminous. 1.0 FILL FILL: Poorly Graded Sand with Silt, fine- to medium- grained, with Gravel, brown, moist. _ 17 4.0 SP- POORLY GRADED SAND with SILT, fine- to medium - grained, SM with Gravel, light brown, moist, medium dense. (Glacial Outwash) 17 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -35 page 1 of 1 B RAC! N' NTE RTES: LOG OF BORING Braun Project BL -13 -05734 BORING: ST -36 GEOTECHNICAL EVALUATION LOCATION: See attached sketch. 2014 Street Reconstruction Project Various Locations Lakeville, Minnesota DRILLER: S. McLean METHOD: 3 1/4" HSA, Autohammer DATE: 9/13/13 SCALE: 1" = 4' Depth feet ASTM Description of Materials BPF WL Tests or Notes 0.0 Symbol (ASTM D2488 or D2487) PAV 6 inches of bituminous over 6 inches of aggregate base. 1.0 POORLY GRADED SAND with SILT, fine- to medium - grained, SP- SM with Gravel, brown, moist, medium dense to dense. (Glacial Outwash) _ 26 31 6.0 END OF BORING. Water not observed to cave -in depth of 4 feet immediately after — withdrawal of auger. — Boring then backfilled. Q) Q U N N 0 N N S BL -13 -05734 Braun Intertec Corporation ST -36 page 1 of 1 APPENDIX E Neighborhood Informational Meeting Minutes — August 13, 2013 August 13, 2013, Public Comment Summary Flagstaff Avenue Public Comment Summary Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 W SB WSB de Assoc engineering- planning• environmental- construction Memorandum To: Steve Mielke, City Administrator Chris Petree, Public Works Director Troy Grossman, Streets Superintendent Zach Johnson, City Engineer Mark Hansen, Assistant City Engineer From: Monica Heil, Project Manager Date: August 15, 2013 Re: City Project No. 14 -02 WSB Project No. 2109 -39 701 Xenia Avenue South Suite 300 Minneapolis, MN 55416 Tel: 763 - 541 -4800 Fax 763 - 541 -1700 A Neighborhood Meeting was held on Tuesday, August 13, 2013 to discuss the proposed 2014 Street Reconstruction Project, City Project #14 -02. Approximately 120 residents attended the meeting held in the Lakeville City Hall Council Chambers to discuss the proposed improvements. The following Staff and WSB & Associates, Inc. representatives were in attendance: • Chris Petree, City of Lakeville, Public Works Director • Troy Grossman, City of Lakeville, Streets Superintendent • Mark Hansen, City of Lakeville, Assistant City Engineer • Monica Heil, WSB & Associates, Inc. • Chris LaBounty, WSB & Associates, Inc. The following is a summary from the Question and Answer portion of the presentation: Question #1 (Ql): Are corner lots treated differently for assessments? Answer #1 (Al): Corner lots are not treated differently under the City's Assessment Policy. Assessments are unit based for residential properties with no difference due to property size or footage adjacent to the project. Q2: Are the temporary mailbox locations permanent? A2: The locations of the temporary mail boxes will not permanent, and mail delivery to these temporary locations will only be implemented as needed during construction. Temporary mailboxes will be needed along streets where complete curb and gutter replacement is St. Cloud • Minneapolis • St. Paul Equal Opportunity Employer wsbeng.com K:\ 02109- 390\Admin\Meeting\Neighborbood Meeting\08 -14 -13 2014 SCP Neighborhood Meeting Minnt —d— City of Lakeville 2014 Street Reconstruction Project Meeting Minutes August 15, 2013 Page 2 proposed. In areas of spot curb and gutter replacement, mailboxes will only be removed as necessary to facilitate the curb replacement. Q3: Will there be "issues" if we have a private contractor working on our home next summer during the street reconstruction project? A3: The City's contractor and your private contractor will need to work together to facilitate work on your private property. Q4: What does the construction schedule look like? We have a graduation party planned for next summer. A4: The project schedule will be better - defined once a contractor is selected for the project, in late spring, 2014. Another neighborhood meeting will be held prior to starting construction to address more specific questions regarding schedules, construction access and general construction concerns. Residents will be mailed the construction representative contact information, as well as a project phasing map, prior to starting construction. Residents can also sign up for the City's e -mail listsery to receive updates about the project. Staff will work with residents to minimize impacts to special events whenever possible. Q5: With all of the kids walking to school and people crossing Flagstaff Avenue, what can be done to improve pedestrian safety? A5: There are many possible solutions to address concerns like this. The City cannot change the traffic volumes along public roads, but will look into traffic calming and safety improvements as part of the feasibility and final design of this project. Q6: Will the project have the surmountable or barrier -style curb and gutter? A6: Curb and gutter throughout the project area will be replaced to match the existing curb types. Q7: How many years will people be paying the assessments and will this time frame change? If you sell your property you are still required to pay the assessment? A7: The assessment period for street reconstruction projects is 20- years. Property owners will be given the option to pay their assessment prior to December 31, 2014, either partially or in -full, to avoid interest charges. Special assessment deferments are available in some situations. Please refer to the City's website for additional information regarding special assessment deferrals. Requirements for paying off your assessment differ by mortgage agreement, but typically mortgage companies do require the remaining assessment be paid off at closing. Q8: Why wasn't Garcia way done with the rest of the project from last year? Property owners in this area will now be dealing with construction in the area for three consecutive summers. A8: The City has not had the capacity over the last few years to add that area. The City has aggressively tried to increase the size of the project areas to minimize such K:\02109- 390\Admin\Meeting\Neighborhood Meeting\08 -14 -13 2014 SCP Neighborhood Meeting Minutes.do City of Lakeville 2014 Street Reconstruction Project Meeting Minutes August 15, 2013 Page 3 inconveniences, and apologizes to those residents that will experience construction activity for multiple years. Q9: Is the City planning on putting new curb and sidewalk in the Dodd Pointe area? Will the City install sidewalks where there are school bus stops, or widen the sidewalks south of the townhomes on Flagstaff? These sidewalks aren't usable during winter because they are too narrow to plow. A9: Curb and gutter is proposed to be removed and replaced in -kind in this area, but no new sidewalks are planned to be installed, nor are any existing sidewalks proposed to be widened as part of the project. However, the City welcomes input from residents regarding additional sidewalks requests. If neighbors can agree on the placement of a new sidewalk, the City will review the request and determine if it is feasible to add the additional sidewalk to the scope of the project. The City is responsible for plowing sidewalks in front public property (i.e. City parks, City buildings, etc.), but plowing sidewalks in front of private property is the responsibility of the property owner. Some sidewalks which are icing over in the winter will likely be corrected with this project, as the boulevards will be re- graded with the installation of new curb and gutter. Q10: Why does Flagstaff Avenue have so many heavy vehicles traveling along it if it's a local City street, and not a County Road? The issue with the deteriorating Flagstaff Avenue pavement is the number of large vehicles using the road. Can load restrictions along Flagstaff Avenue be added to the scope of the project? Al 0: Flagstaff Avenue is classified as a major collector in the City's Comprehensive Transportation Plan, and is intended to keep heavy vehicles off of local streets. Public streets are designed for public use, and the City has found it difficult to limit or enforce weight restriction policies. Q11: For existing concrete driveways, will the City "patch" that portion of the concrete driveway to the nearest expansion joint? Are the driveways going to be replaced to wider widths than they exist? All: With concrete driveways, the City's practice has been to remove and replace the driveway to the first joint and to replace the driveway to match its current width. Within the City of Lakeville, driveways can be a maximum of 24 -feet in width, unless a permit is obtained to construct the driveway to 28 -feet in width. The City plans to patch disturbed driveways to match their existing widths unless otherwise requested by the property owner. Q12: How far into my driveway will the pavement be removed with the street improvements? Al2: Typically, only the first 3 -to -5 feet of a driveway are disturbed with the curb and gutter improvements. However, if more extensive improvements are need to correct grading /drainage issues, or to install additional storm sewer improvements, the maximum distance that would be disturbed is 14 -feet behind the back of curb, which is the City's right -of -way limits. K:\02109- 390\Admin\Meeting\Neighborhood Meeting\08 -14 -13 2014 SCP Neighborhood Meeting Minutes.do City of Lakeville 2014 Street Reconstruction Project Meeting Minutes August 15, 2013 Page 4 Q13: What does the City do with broken mailboxes or custom mailboxes? A13: If a mailbox isn't salvageable or the post is deteriorated beyond the point of salvaging, the City will replace with a standard mailbox and /or mailbox post. If the property owner decides to purchase a different mailbox while construction is underway adjacent to their property, the City will work with the property owner to install this new mailbox in conjunction with the project. Q14: What if a boulevard tree dies due to root damage associated with the street reconstruction project a few years down the road? A14: The contractor warranty period for work completed with the project is 1 -year, but the City would still like to hear from you even if something like this were to happen outside of the contractor warranty period. The City does also work with a certified arborist minimize situations like this. Q15: Once work on the project begins, is it too late to point out issues /concerns? A15: Once construction commences, the best points -of- contact will be the on -site construction representatives, and those representatives can work with property owners to resolve issues that come up during construction. Q16: Will the City lower the street for drainage improvements? A16: It depends on the circumstances in any given area. Typically with street reconstruction projects, any changes in the vertical elevation of road are made to improve the drainage conditions in the neighborhood. Q17: If there trees are within 6 -feet of the existing curb and gutter within the Niakwa Village area, will they be impacted? How far from the back of curb are trees removed? A17: The factors that necessitate the removal of any given tree within a street reconstruction project area are varied: The location of the curb removal in relation to the tree; if the tree is currently causing damage to the street or curb (i.e. heaving); or if the tree species has potential to cause damage to the roadway in the future (i.e. silver maples). The City will be identifying trees to be removed as part of the feasibility report and final design phases of the project. Q18: I'm concerned with children on Flagstaff walking to school. Are walking routes planned for students walking during construction? A18: The City works to phase construction around the school year and in school areas to minimize impacts to students. The City also works with the school district to minimize impacts. Safety is the primary concern for everyone involved with a City construction proj ect. Q19: Until the reconstruction work actually commences on the project, can we please work to make the streets more passable? Fire trucks are bottoming out due to poor roadway conditions. Also, what happens if a car is damaged due to a pothole? A19: The City continues to work to address the poor roadway conditions in the project area. However, with the planned reconstruction for next year, the City will perform minimum maintenance in this area, mainly patching where there are safety issues and to ensure snow plows and emergency vehicles maneuver the streets. KC\ 02109- 390\Admin\Meeting\Neighborhood Meeting\08 -14 -13 2014 SCP Neighborhood Meeting Minutes.do City of Lakeville 2014 Street Reconstruction Project Meeting Minutes August 15, 2013 Page 5 Regarding claims for damage resulting from potholes, previous case law has shown that the City's insurance will not cover this damage. Q20: When I need to park on the street due to the concrete curb and gutter /driveway curing time period, how will the City address the traffic and fast speeds of drivers passing through the neighborhood? A20: During construction The City will have the roads closed to local or "thru" traffic. Police patrols are also informed of street reconstruction activity and are aware that issues such as this will need to be monitored. Q21: Is there a reason why the final paving from the 2012 project wasn't completed until a few weeks ago? A21: There was a significant amount of water main and underground utility work in this area, and the City wanted to allow that area to go through a freeze /thaw cycle to identify any problems prior to placing the final lift of pavement. Q22: When driveways and curbs are removed for construction, is the gap temporarily filled in? A22: The contractor will provide gravel ramps during construction to provide access. Q23: How else can residents learn about plans for traffic calming on Flagstaff Avenue? Are the driver feedback signs currently on Flagstaff Avenue going to become permanent fixtures? Has the City looked at opportunities to reduce vehicle speeds along Flagstaff Avenue south of Dodd Boulevard (CSAH 9)? A23: The City plans to identify traffic calming options with the feasibility report for the project, but would also like feedback from residents along Flagstaff Avenue about some of the proposed solutions. The driver feedback signs currently located along Flagstaff Avenue will be made permanent fixtures with the 2014 Street Reconstruction Project (in the same general locations). Speed limits are set by state statue and a speed study would be required by MnDOT in order to modify any posted speed limits along a local street. A speed study for Flagstaff Avenue was recently completed, and the current posted speed limits reflect the results of that study. Q24: Are we going to put additional catch basins in with the project? If we have a drainage structure that is "flooding," can that be addressed? A24: These meetings are a great opportunity to have residents identify areas where we have drainage issues like this. Yes, it is anticipated that some additional storm sewer facilities will be constructed with the street improvements. Residents are encouraged to use the markers attached to the presentation boards at the back of the room to write notes about site /drainage issues in the neighborhood. If there are existing conditions which are causing problems, we'd like to have you fill out a comment card and during final design staff will look at addressing these issues. KC\ 02109- 390\Admin\Meeting\Neighborhood Meeting\08 -14 -13 2014 SCP Neighborhood Meeting Minutes.d— August 13, 2013 Public Response for Project Pre -Neighborhood Meeting Phone Conversations Item# Resident Name Resitlent Atltlress Phone Oat.Received Comment Res o Resitlen(wantetl to know whyth a City— reconstructing Flagstaff A,,nuein 2014 Monica Heil rssp.nd.d that Flagstaff Avenue was being constructed now because of 1 Valerie Smith 16401 Flagstaff AV enue 952 -031 -4282 8/5/2013 when the rtl avetl it in 2001. its curers condition ratin Resitlent know what impmvemed, were proposed, It he, taxes would Monica Heil explained that the pmjactincluded complete street reconstruction , stone a w,nledt, rssA ofthe prose, how much the assessm,w , and how endoudd be rovem impents and spot sidewalk replacement Monica Heil indicated the 2 Mohammed. Buchanan 16271 Fougmen Avenue 952- 953-0324 8/5/2013 rasidentscould getinfoer.han a bout the neighborhood meeting ff(hey could not .tend . specal rise..ad, could be y taxes, and that a range of ment.mountswouMl p— ,dedatth.n.,ghborhoodm -t,.g. Formselents that are unable to attend the neighborhood meeting, the information will bs posted orm. for resid.nts,flerthe meelin Residentisintha processo fhavi nghe rexi stingb ituminousdrvewayreplacedtoday Monica Heilaxplainedihet yes, the drvew ay...IdbeimpactM.dhthecurban She wanted to know if her new driveway was going to have a patch in it next year aRer Sutler replacement proposed as a pad of the protect. Resitlent asked Rthe mntractor the street improvements are completed. Resident wasymy upset that no notice was working on the 2013 Street ReconsWct.n Protect could come and replace the curb. 3 Laura Kleven 6026 Lower 167 s1 Street 952 -997- 7431 8/6/2013 given to residents about, potential preterit is this area prior to th - ¢ neighborhood front of her house th¢ summer so it wouldn't need to be replaced next year Monica —phon Heil indicated that was not an option_ Resitlent very upselihat no notice was given r letter acting notice, ,nd that the City couleft work amu ntl her drvway next year with( he street improvement project ,boulthep ootl Resitlent, unable to attend neighborhood meeting_ Had questions leoultim scope of Monica Heil advised all neighborhood meeting materials woultl be posted online Becky Lillehei and the improvements and potential assessments. f (lowing the neighborhood meeting_ Indicated assessment ranges would be 4 Steve Lot— Way 952E91E053 8/62013 presented at the neighborhood meeting_ Biscussed—urfurne improvements to presented Geor clown Wa _ 5 To mmy Johnson 6183162nd Street 952 -031 - 1945 8/6/2013 Resident wondered how long the streets would be "ripped -up" with contraction, ahead ant am ounts and access dune construction_ Monies Heil answered general q rashers and indicated that neighborhood meeting materials would be posted on Thum after the Meetin next week. Resitlent had questions,bout the seepe ofwork and ift1,ers would be assessments. Chris Petrse informed herthat in herarea,a majority oTiF. curb could remain in place fi Julie Swanson 170th Street 8/] /2013 with some repairs to the storm sewersystem and a rsclamation oithe mad surtace. 952- 953 -9736 He also informed herthat there would be assessments_ 7 Judy Glenn W70 169th Street 952 - 334-5811 8/912013 Resitlent is cuneMy caF oTstht., bulwarted to call to indicate she was in suppod of the - act_ Resident had questions abouldrveway patch work /rsplacement work associated with Monica Heil returned call and leflvoicemail message that all information Fran the 8 Ricky Frazier 16154 Fishing Avenue 952607 -7853 8/122013 the prgect, and is unable to attend the meeting neighborhood meeting would be posted online on the Citys welood. by the end f the week_ 9 .Jahn Zschure, 16217 Fantasia Avenue 952- 250-9162 8/132013 Resitlent was unable to attend the neighborhood meeting and wanted to know if he ceukl obtainre ies of an information the distributed at the Meetin _ Monica Heil in l-fiel that copies of all meeting materials would hs posted on the City. w.bsd. by the .nd of the week_ 10 Lisa McCarthy I 16513 Fishing Avenue 952- 221 - 1860 8/14/2013 Resid ent was unable to attend he neighborhood meeting and wanted to know if she could obtain copies of an inform anon that was distributed at the cmatum Monica Heil indicated that copies of all meeting materials would be posted on the City's lw,b,d, by the and of the week. Public Informational Meeting - 8113113 Hard # Resident Name Resitlent Atltlress Phone Oat. Received Comment Res o Could we change the 169th and Lower 169th St_ W thomughfair to add some speed 1 Becky Palmer W45 LOwar 16911, St. W 952 -131 - 1858 8/132013 bum ps instead ofthe signs oalsel,th, area forhunuhng trafrcto no entrance belween4 4 in off Bcdd or the otheroble that sa between 46 a m_ 2 Ann Samurai 16381 Fernando Way 952 -131304 8/132013 The mad in front of our m ailbox is low and we and up with .skating rink each spring. My wife and I would potentially harm be—of truth, calming menu rss but first and fors. osl shou It be some stricter enforcement. 1 am the ducky homewner Nat has a speed sign (now parnanartH u myyard. 1 ratunkrysee carsdriving 1015 -20 milesan 3 Justin Boller 16608Flagstaff AVe. W 612 - 9856973 8/132013 hou r war the speed limit and it is mdearly tare that l see a police patrol_ Why ,van n sider spending more money without beef g up patrols in the area? Please hold future meetings before moving fonval with orwilhoul trathc cabling plans_ Fertile cord, not really happy about a permanent speed sign in myyam bringing down property ulna How long will our street lot 1,l not be working or will they continue to wode2 It Finch will 4 Jan Lanier 6285161 St W 952432 -1978 8/132013 can the road be milled down se it is laved, Us dangemus to go from Finch onto 1601h.-roccallm the wintann Bon and Judy Living on Flagstaff AVe is a mess to get into orout of our driveways. F-ing the truth, 5 Aus.as 16515 Flag staff Avenue 952 -03245181 8/132013 is great but a signal light at all intersections to g ve residents a chance to get out without a honking hem or cuss estum_ Somthma needs to be done_ 6 Tom ,ntl Sandy Saunders 16154 Flagstaff AVe W 952 -032 -0239 8113/2013 We ,u000d traffic slowing consums on Flagstaff Avenue_ Selmalks in front of 16616 Flagstaff Ave W sinks and is problem in winter. Snow 7 Anne A,hf M 1W16 Flagstaff AVe W 952-132 -2792 8/132013 Quad takes sed from both sides esitlwalk.nd has not been repaired in spring_ Need stoplight to contend speed and hopefudly eliminate some of the semi truth,. August 13, 2013 Public Response for Project 8 Pam Dosenow 62701614 St W 612 - ]944156 8/132013 Level Finch Ave at entrance to 100th. Consitlersitlewalks in wootls area of Georgetown VV6y- Gertline. Neighborswoultl 9 Err, SUnsdahl 170th &Georgetown 651 - 346-9222 8/132013 have to a rove basatl on $_ 10 Karen Jacmbson 16207 Excelsior Circle 952 -037 4976 8/13/2013 Please check tlrainage on comerd Excahaar Dr &Exdo —r Carla Constantly pools after rain antl ¢ an ice' ntl in winter. 11 Carol Miszamr 17083 Geo ,town MV 8113/2013 Constmd a Id-11, fmm GOO ,town Wa to Gertline Path forwalkion Drain on west sitle of Flagstaff AVe at163rtl(n front of my house) ffootls most every 12 Mike H-d—on 16245 Flagstaff AVe 952- 250-979] 8/13/2013 rainfall. Nood fixin s mehow. 0 en to wid nand sit -11s. Comment Cards /Letters Item# Resident Name Resident Address Phone Date Ra(xivetl Comment Res o Crosswalks forschool chiltlmn - I have observetl children crossing Flagstaff Avenue at 163M St to catch bus on NE comer of intersection- Cars at that time of day (7 -7.30 and a is -chool in p m ) ere sualdy speetling and "T" is wre ta d Most cars 1 Carmen Can—fu 16226 H Flagstaff AVe W 95M91 -0410 do not stop far th, kitls, or may slop ar no dha ion but not the other Kkls are running oss, jumping snow banks, cartying heavy backpacks and musical instmment cases_ VERY DANGEROUS scary to watch_ Not wo dtingthiscabntlaryearalbwetlmeto ob,,,, fmm my home. Suggest -nor to d run— Ac with pedestrian light to stop traffic. 1 ntten ia, the recent meeting_ There was a Iol of info_ My main interests will be the ant cost s, calming traffic, antl removal of curbsitle trees_ haveadyingash 2 Larry Sisk 16701 Flagstaff AVe 952 -032 -]605 tree curbsitle which is an eyesore _Many ofthe ash trees on Flagstaff are. not healthy or pretty Since I am across fmm the firehall, is that a place I could park tluing the 5 day penotl rfnecessary? Keep me ,—d! of future meetings or actions_ Follow-Up Inquires Ikm# Resident Name Resident Address Phone Date Received Comment Res o Resitlend cdlletl with questions mgading mail tlelrverytluring c— Mrtion, the timeline Monica Heil answeretl general questions, and tleectetl herb the 2014 Street for construction, bee removal (her pine tree is 16 +feet fmm the curb stop, 18 + feet Reconstmcfion Project website fa— forno.han fmm the Neighborhoa Meeting as well 1 Marilyn Olson 16910 Garcia Way 952-432- 1464 8/142013 fmm the back-0 t -curb), I told her to,e oa what she was d —nbing for the tree. as the 2013 Street Reconstru ctionProtect website brinformali.n on special location,herp,n. bee tlid not sound lke it...Id be tlistu roar, and dferments for ess.ents brsenior citizens. or zens. Monica Heil bfta voice mail message with information on how to access answers to 2 Chris 952 - 215-2459 8/142013 Re dnet had questions about irgatun, systems that may be unpacted with the project such uestons on the Ci 's website for Ne act R-d—t left message slating he had general questions about the project Monica Had Iefta voice..A message wilh information on how to access answers to 3 Jarad 651- 3943594 8/152013 1 iral uestions on the Ci .to,le for the - act. Resitlend hatl questons about the cost of the protect antl the pmposetl schetlule_ Monica Heil left a message with cost antl schetlule information, antl at. da"tetl this 4 Howard Howell 6165162nd Street 763-5863126 8/1 5201 3 no,ki-1 to the Citys website forth, project to view add,t,onnl information from the Au ust 13 2013 Nei hborhoatl Meetin 5 M,Iissa Ellingson 612- 7166988 8/152013 Resitlent left message that she had questions about the project Monica Hen Iefta voice mail message with information on how to access answers to forth, - act_ t iral uestons on the Ci swebsiss.enl Resitlend caned with questions about assessment amounts and repayment terms- questionsto Monica Heil answeretlgeneralasse; tlimcted residenito the Gdys 6 Keith And.— 6075 Lower 161st Street 952 -031 -]373 8/152013 webste bratltlitional information from Tu,s , 's Ne htwrhood Meetin _ 7 Jim Me r 16501 F,,,nd,WV 952 -032 -3950 8/162013' Resitlenl called uestin ne hborhootl meetin materials_ Monica Heil em ailetl materiak to amesm, er fmntiem,tnot Resitlenl einailetl with questions about stampetl /cobred tlrvewaY impacts. Monica H- ilemailed back that we will lode foropportunities to work around the 8 Karla Berg 16062 Fishing venue .nkbandUrbimail 8/15 /2013 drveway Suggestod we tliscuss again at the sprang neighborhood meeting br the 'eG and selatla /time forfeltl staff lomeet wnh hr thes nn well Resitlenl had concerns about cmnstmctidn tlusl antl access tlunng construction next Monica Heid offeretl to havefieddstaff.eelwith resitled next sprang to tliscuss 9 John Collins 16510 Flagdad Avenue 651 -302 -1245. 8812013 year,wiffi is dying antl has sever health issuesltlustcoultl worsen her contlition _Also cers_Alsoanswemtl general assessment and lateral questions. had uestions about assessments antl d,ferrds_ 10 Carol Pitcher 17031 Georgetown Way 1 612-9862196 8/22/2013 Resitlend left Monica Had a message that she had questions about the project Monica Had returned call and left voice. ail message that all information fmn the ei hborhood meetin b Wtd online on the Cit s website_ 11 Tod i Alto 6201 162nd Street 912- 7263060 8/30/2013 Resitlenl hatl uestions about the curb t f rn— taldation. Mona He m left a vch -nor Iacetl un,Aand icil il mesa a that the curbwoultl be - Resitlenlhatl concerns about the safely of the intersection of Fangreen Avenue antl Monica Heil to relay concerns about idersedion safety(. Chris Pat—so he can relay 12 Gustavo Rudrguez 16306 Fairgreen 952 -086-0053 9/10/2013 .-d Bcad— M- wantetlatumlaneon Dodd fir Favgreen. Also ova ftal school bus to Dakota County stop bcation .—d awayfrom the intersection of Fa,M—n and Dadd Resal -th questions about the pmpsed assessments for propedies along Foliage M onus Heil answeretl th¢ rooded's general q uestions. 13 Gerry Grenz 952432 -1789 10/3/2013 Avenue an the estimated assessment amounts. Flagstaff Avenue Public Response for Project Comment Cards /Letters Item # Resident Name Resident Address Phone Date Received Comment Respo "I like the idea for bump cut on Flagstaff Avenue and I am all for it. I would like to see the catch basin /drain gutter relocated however that is at the end of my driveway. 1. It catches debris and plugs up when it wins heavy, causing flooding into the road, my 1 Mike Hederson 16245 Flagstaff Avenue 952 - 250-9794 1013/2013 driveway, and yard. 2. 1f bumpouts are installed, this 'gutter would then actually be in the new extended portion of my driveway. Also like the idea of 2 additional driver feedback signs. Thought - smaller stop lights at Flagstaff and 164th Street/Gerdine. Widen sitlewalks ?" 'My concern is the approximately 200 yards to the north of the last bum pout This is 2 E. F. Smith 16064 Flagstaff Avenue 952 -431 -3224 10/3/2013 the area that vehicles speed up to make the stop light on 160th. They almost fly over 160th going slow to. There is quite a number ofjoggers, cyclists, and pedestrians in this area and gives me cause for c "1 woultl like to see 5' sitlewalks. woultl not like to have a bump out in front of my 3 John Englund 16504 Fkagstaff Avenue 952 -4323781 10/3/2013 house. like on street Arkin Thank o "I would really like to see a stop sign at the 4 -way stop on Flagstaff (164th and 4 Deanna Englund 16504 Fkagstaff Avenue 952 -4323781 1013/2013 Flagstaff) that is lit up with the LED lights (like the ones in Burnsville, near Crystal Lake . woultl like to have the 5 ft sidewalks installed." "VJe are for wider sidewalks. We a e right across from the 1st bump out proposed on 5 Jon Kinnard 16172 Flagstaff Avenue 612 - 735 -2398 10/3/2013 the west side of Flagstaff and are not opposetl to having a bumpout on the east as well." APPENDIX F Soil Corrosivity Results /Past Project Comparison Feasibility Report 2014 Street Reconstruction Project City Project No. 14-02 City of Lakeville, MN WSB Project No. 2109 -391 Corrosivity of Soils Based on ANSI /AWWA C105 *Score of 10 points indictes that soil is corrosive to ductile iron pipe and protection is needed 2012 Street Reconstruction Project Street Name Score Gannon Way 12 Gannon Way 12 Gannon Way 12 Gerdine Path 12 Lower 170th Street Court 10 Galaxie Way 12 Galaxie Way 12 2013 Street Reconstruction Project Street Name Score Ixonia Avenue 12 Iteri Avenue 10 208th Street 3 Isle Avenue 2 Iran Avenue 7 2014 Street Reconstruction Project Street Name Score Garcia Way 13 Garcia Way 11 170th Street 13 Georgetown Way 11 170th Street 16