Loading...
HomeMy WebLinkAboutItem 06.d• • • • • ☐ AGREEMENT BETWEEN CITY OF LAKEVILLE AND HERTAUS FLOORS, INCORPORATED FOR FLOORING PROJECT AT THE LAKEVILLE POLICE DEPARTMENT THIS AGREEMENT made this 18TH day of February, 2020, by and between the CITY OF LAKEVILLE, a Minnesota municipal corporation (“Owner” or “City”) and HERTAUS, FLOORS, INC. (“Contractor”). Owner and Contractor, in consideration of the mutual covenants set forth herein, agree as follows: 1. CONTRACT DOCUMENTS. The following documents shall be referred to as the “Contract Documents”, all of which shall be taken together as a whole as the contract between the parties as if they were set verbatim and in full herein: A. This Agreement. B. Contractor’s Proposal dated January 16, 2020. In the event of a conflict among the provisions of the Contract Documents, the order in which they are listed above shall control in resolving any such conflicts. Contract Document “A” has the first priority and Contract Document “B” has the last priority. 2. OBLIGATIONS OF THE CONTRACTOR. The Contractor shall provide the goods, services, and perform the work in accordance with the Contract Documents. Contractor shall not begin any work until the City has received the signed contract and has reviewed and approved the insurance certificates and has given the Contractor a written notice to proceed. Contractor shall exercise the same degree of care, skill, and diligence in the performance of the services as is ordinarily possessed and exercised by a contractor under similar circumstances. City shall not be responsible for discovering deficiencies in the accuracy of Contractor’s services. 3. CONTRACT PRICE. Owner shall pay Contractor for completion of the Work, in accordance with the Contractor’s Proposal. Additional work performed without the City’s written approval will not entitle Contractor to an increase in the Contract Price or an extension of the Contract Time. 4. PAYMENT PROCEDURES. A. Contractor shall submit Applications for Payment. Applications for Payment will be processed by the Police Department. B. Progress Payments; Retainage. Owner shall make 95% progress payments on account of the Contract Price on the basis of Contractor’s Applications for Payment during performance of the Work. C. Payments to Subcontractors. (1) Prompt Payment to Subcontractors. Pursuant to Minn. Stat. § 471.25, Subd. 4a, the Contractor must pay any subcontractor within ten (10) days of the Contractor’s receipt of payment from the City for undisputed services provided by the subcontractor. The Contractor must pay interest of 1 ½ percent per month or any part of a month to the subcontractor on any undisputed amount not paid on time to the subcontractor. The minimum monthly interest penalty payment for an unpaid balance of $100.00 or more is $10.00. For an unpaid balance of less than $100.00, the Contractor shall pay the actual penalty due to the subcontractor. (2) Form IC-134 (attached) required from general contractor. Minn. Stat. § 290.92 requires that the City of Lakeville obtain a Withholding Affidavit for Contractors, Form IC-134, before making final payments to Contractors. This form needs to be submitted by the Contractor to the Minnesota Department of Revenue for approval. The form is used to receive certification from the state that the vendor has complied with the requirement to withhold and remit state withholding taxes for employee salaries paid. D. Final Payment. Upon final completion of the Work, Owner shall pay the remainder of the Contract Price as recommended by the Police Department Deputy Chief. 5. COMPLETION DATE. The Work must be completed between May 13 - May 20, 2020. 6. CONTRACTOR’S REPRESENTATIONS. A. Contractor has examined and carefully studied the Contract Documents and other related data identified in the Contract Documents. B. Contractor has visited the Site and become familiar with and is satisfied as to the general, local, and Site conditions that may affect cost, progress, and performance of the Work. C. Contractor is familiar with and is satisfied as to all federal, state, and local laws and regulations that may affect cost, progress, and performance of the Work. D. Contractor does not consider that any further examinations, investigations, explorations, tests, studies, or data are necessary for the performance of the Work at the Contract Price, within the Contract Times, and in accordance with the other terms and conditions of the Contract Documents. E. Contractor is aware of the general nature of work to be performed by Owner and others at the Site that relates to the Work as indicated in the Contract Documents. F. Contractor has correlated the information known to Contractor, information and observations obtained from visits to the Site, reports and drawings identified in the Contract Documents, and all additional examinations, investigations, explorations, tests, studies, and data with the Contract Documents. G. The Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. H. Subcontracts: (1) Unless otherwise specified in the Contract Documents, the Contractor shall, upon receipt of the executed Contract Documents, submit in writing to the Owner the names of the Subcontractors proposed for the work. Subcontractors may not be changed except at the request or with the consent of the Owner. (2) The Contractor is responsible to the Owner for the acts and omissions of the Contractor's subcontractors, and of their direct and indirect employees, to the same extent as the Contractor is responsible for the acts and omissions of the Contractor's employees. (3) The Contract Documents shall not be construed as creating any contractual relation between the Owner and any subcontractor. (4) The Contractor shall bind every subcontractor by the terms of the Contract Documents. 7. WORKER’S COMPENSATION. The Contractor shall obtain and maintain for the duration of this Contract, statutory Worker’s Compensation Insurance and Employer’s Liability Insurance as required under the laws of the State of Minnesota. 8. INSURANCE. Prior to the start of the project, Contractor shall furnish to the City a certificate of insurance showing proof of the required insurance required under this Paragraph. Contractor shall take out and maintain or cause to be taken out and maintained until six (6) months after the City has accepted the public improvements, such insurance as shall protect Contractor and the City for work covered by the Contract including workers’ compensation claims and property damage, bodily and personal injury which may arise from operations under this Contract, whether such operations are by Contractor or anyone directly or indirectly employed by either of them. The minimum amounts of insurance shall be as follows: Commercial General Liability (or in combination with an umbrella policy) $2,000,000 Each Occurrence $2,000,000 Products/Completed Operations Aggregate $2,000,000 Annual Aggregate The following coverages shall be included: Premises and Operations Bodily Injury and Property Damage Personal and Advertising Injury Blanket Contractual Liability Products and Completed Operations Liability Automobile Liability $2,000,000 Combined Single Limit – Bodily Injury & Property Damage Including Owned, Hired & Non-Owned Automobiles Workers Compensation Workers’ Compensation insurance in accordance with the statutory requirements of the State of Minnesota, including Employer’s Liability with minimum limits are as follows: $500,000 – Bodily Injury by Disease per employee $500,000 – Bodily Injury by Disease aggregate $500,000 – Bodily Injury by Accident The Contractor’s insurance must be “Primary and Non-Contributory”. All insurance policies (or riders) required by this Contract shall be (i) taken out by and maintained with responsible insurance companies organized under the laws of one of the states of the United States and qualified to do business in the State of Minnesota, (ii) shall name the City, its employees and agents as additional insureds (CGL and umbrella only) by endorsement which shall be filed with the City. A copy of the endorsement must be submitted with the certificate of insurance. Contractor’s policies and Certificate of Insurance shall contain a provision that coverage afforded under the policies shall not be cancelled without at least thirty (30) days’ advanced written notice to the City, or ten (10) days’ notice for non-payment of premium. An Umbrella or Excess Liability insurance policy may be used to supplement Contractor’s policy limits on a follow-form basis to satisfy the full policy limits required by this Contract. 9. WARRANTY. The Contractor shall be held responsible for any and all defects in workmanship and materials which may develop in any part of the contracted service, and upon proper notification by the City shall immediately replace, without cost to the City, any such faulty work. 10. INDEMNIFICATION. To the fullest extent permitted by law, Contractor agrees to defend, indemnify and hold harmless the City, and its employees, officials, and agents from and against all claims, actions, damages, losses and expenses, including reasonable attorney fees, arising out of Contractor’s negligence or its performance or failure to perform its obligations under this Contract. Contractor’s indemnification obligation shall apply to subcontractor(s), or anyone directly or indirectly employed or hired by Contractor, or anyone for whose acts Contractor may be liable. Contractor agrees this indemnity obligation shall survive the completion or termination of this Contract. 11. PERFORMANCE AND PAYMENT BONDS. Performance and Payment Bonds are not required. 12. MISCELLANEOUS. A. Owner and Contractor each binds itself, its partners, successors, assigns and legal representatives to the other party hereto, its partners, successors, assigns and legal representatives in respect to all covenants, agreements, and obligations contained in the Contract Documents. B. Any provision or part of the Contract Documents held to be void or unenforceable under any law or regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon Owner and Contractor, who agree that the Contract Documents shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provisions. C. Data Practices/Records. (1) All data created, collected, received, maintained or disseminated for any purpose in the course of this Contract is governed by the Minnesota Government Data Practices Act, Minn. Stat. Ch. 13, any other applicable state statute, or any state rules adopted to implement the act, as well as federal regulations on data privacy. (2) All books, records, documents and accounting procedures and practices to the Contractor and its subcontractors, if any, relative to this Contract are subject to examination by the City. D. All reports, plans, models, software, diagrams, analyses, and information generated in connection with performance of this Agreement shall be the property of the City. The City may use the information for its purposes. E. Patented devices, materials and processes. If the Contract requires, or the Contractor desires, the use of any design, devise, material or process covered by letters, patent or copyright, trademark or trade name, the Contractor shall provide for such use by suitable legal agreement with the patentee or owner and a copy of said agreement shall be filed with the Owner. If no such agreement is made or filed as noted, the Contractor shall indemnify and hold harmless the Owner from any and all claims for infringement by reason of the use of any such patented designed, device, material or process, or any trademark or trade name or copyright in connection with the Project agreed to be performed under the Contract, and shall indemnify and defend the Owner for any costs, liability, expenses and attorney's fees that result from any such infringement. F. In providing services hereunder, Contractor shall abide by all statutes, ordinances, rules and regulations pertaining to the provisions of services to be provided. G. Assignment. Neither party may assign, sublet, or transfer any interest or obligation in this Contract without the prior written consent of the other party, and then only upon such terms and conditions as both parties may agree to and set forth in writing. H. Waiver. In the particular event that either party shall at any time or times waive any breach of this Contract by the other, such waiver shall not constitute a waiver of any other or any succeeding breach of this Contract by either party, whether of the same or any other covenant, condition or obligation. I. Governing Law/Venue. The laws of the State of Minnesota govern the interpretation of this Contract. In the event of litigation, the exclusive venue shall be in the District Court of the State of Minnesota for Dakota County. J. Severability. If any provision, term or condition of this Contract is found to be or become unenforceable or invalid, it shall not affect the remaining provisions, terms and conditions of this Contract, unless such invalid or unenforceable provision, term or condition renders this Contract impossible to perform. Such remaining terms and conditions of the Contract shall continue in full force and effect and shall continue to operate as the parties’ entire contract. K. Entire Agreement. This Contract represents the entire agreement of the parties and is a final, complete and all-inclusive statement of the terms thereof, and supersedes and terminates any prior agreement(s), understandings or written or verbal representations made between the parties with respect thereto. L. If the work is delayed or the sequencing of work is altered because of the action or inaction of the Owner, the Contractor shall be allowed a time extension to complete the work but shall not be entitled to any other compensation. OWNER: CONTRACTOR: CITY OF LAKEVILLE HERTAUS FLOORS, INC. BY: ____________________________ BY: ____________________________ Douglas P. Anderson, Mayor Its: _______________________ AND ___________________________ Charlene Friedges, City Clerk Estimate Date 1/16/2020 Estimate # 1621 Name / Address Lakeville Police Department 9237 183rd St Lakeville, MN 55044 HERTAUS FLOORS, INC 121 E. Main St Suite A New Prague, MN 56071 Terms Project Signature _____________________________________ Thank you for the opportunity to bid your project. Estimate is valid for 30 days unless otherwise noted. Phone # 952-758-5740 Total Subtotal Sales Tax (6.875%) Description Qty Cost Total Shaw Lucky Break 54734 623.61 24.50 15,278.45 Emphatic 54255 carpet base installed 1,000 3.00 3,000.00 Removal & disposal of the existing carpet 620 4.00 2,480.00 ** Option Room 154: If the same carpet is installed with carpet base and removal and disposal of the old flooring the price would be an additional $591.00 Above pricing does not include moving furniture. $20,758.45 $20,758.45 $0.00